JACKSON COUNTY
INVITATION TO BID
RB-2324-11 London Road Roadway Improvements
Sealed bids will be received by the Board of County Commissioners (Owner), of Jackson County, Florida until 2:00 p.m. CST on Thursday, May 16, 2024, at the office of Jackson County Administration, located at 2864 Madison Street, Marianna, Florida 32448, for the road improvement project located on London Road.
Description of Work: The scope of work includes the paving or resurfacing and sodding of London Road, to be completed using the method which is identified in the related bid documents. Roads included in this project are:
London Road, (4,981 LF X 18FT)
Pre-bidding questions regarding the project may be addressed to Lynsey Darragh, Procurement Officer, at [email protected].
Bids will be opened and recorded at 2:00 PM CST (or shortly thereafter) on Thursday, May 16, 2024, at the Jackson County Board of County Commissioners Office at 2864 Madison Street, Marianna, FL 32448. Sealed bids can be received at the above address, or electronically via www.centralbidding.com.
Specifications and Contract Documents will be made accessible at www.centralbidding.com, or by contacting Lynsey Darragh, Procurement Officer by email at [email protected].
Board of County Commissioners
By: Paul Donofro, Jr.
BOARD CHAIRMAN
Clayton O. Rooks, III
CLERK OF CIRCUIT COURT
L7267 Dates of Publication: 04/25/2024, 05/02/2024
JACKSON COUNTY
INVITATION TO BID
RB-2324-10 Sylvania Plantation Roadway Improvements
Sealed bids will be received by the Board of County Commissioners (Owner), of Jackson County, Florida until 2:00 p.m. CST on Thursday, May 16, 2024, at the office of Jackson County Administration, located at 2864 Madison Street, Marianna, Florida 32448, for the road improvement project located on Sylvania Plantation Road.
Description of Work: The scope of work includes the paving or resurfacing and sodding of Sylvania Plantation Road, to be completed using the method which is identified in the related bid documents. Roads included in this project are:
Sylvania Plantation Road, from Hwy. 69N, (6,000 LF X 18FT)
Pre-bidding questions regarding the project may be addressed to Lynsey Darragh, Procurement Officer, at [email protected].
Bids will be opened and recorded at 2:00 PM CST (or shortly thereafter) on Thursday, May 16, 2024, at the Jackson County Board of County Commissioners Office at 2864 Madison Street, Marianna, FL 32448. Sealed bids can be received at the above address, or electronically via www.centralbidding.com.
Specifications and Contract Documents will be made accessible at www.centralbidding.com, or by contacting Lynsey Darragh, Procurement Officer by email at [email protected].
Board of County Commissioners
By: Paul Donofro, Jr.
BOARD CHAIRMAN
Clayton O. Rooks, III
CLERK OF CIRCUIT COURT
L7266 Dates of Publication: 04/25/2024, 05/02/2024
NOTICE OF INTENT TO DESIGNATE
POSITION FOR INCLUSION IN SENIOR
MANAGEMENT SERVICE CLASS
Notice is hereby given by the Jackson County Board of County Commissioners of the intent to designate the position of Deputy Emergency Management Director to be included in the Senior Management Service Class with the State of Florida Retirement System.
L7271
Dates of Publication: 04/25/2024, 05/02/2024
JACKSON COUNTY
INVITATION TO BID
RB-2324-12 Bright Prospect Road Roadway Improvements
Sealed bids will be received by the Board of County Commissioners (Owner), of Jackson County, Florida until 2:00 p.m. CST on Thursday, May 16, 2024, at the office of Jackson County Administration, located at 2864 Madison Street, Marianna, Florida 32448, for the road improvement project located on Bright Prospect Road.
Description of Work: The scope of work includes the paving or resurfacing of Bright Prospect Road, to be completed using the method which is identified in the related bid documents. Roads included in this project are:
Bright Prospect Road, Hwy. 167 to end of pavement (3,472 LF X 20FT)
Pre-bidding questions regarding the project may be addressed to Lynsey Darragh, Procurement Officer, at [email protected].
Bids will be opened and recorded at 2:00 PM CST (or shortly thereafter) on Thursday, May 16, 2024, at the Jackson County Board of County Commissioners Office at 2864 Madison Street, Marianna, FL 32448. Sealed bids can be received at the above address, or electronically via www.centralbidding.com.
Specifications and Contract Documents will be made accessible at www.centralbidding.com, or by contacting Lynsey Darragh, Procurement Officer by email at [email protected].
Board of County Commissioners
By: Paul Donofro, Jr.
BOARD CHAIRMAN
Clayton O. Rooks, III
CLERK OF CIRCUIT COURT
L7268 Dates of Publication: 04/25/2024, 05/02/2024
JACKSON COUNTY
INVITATION TO BID
RB-2324-13 Thompson Road Guardrail
Sealed bids will be received by the Board of County Commissioners (Owner), of Jackson County, Florida until 2:00 p.m. CST on Thursday, May 16, 2024, at the office of Jackson County Administration, located at 2864 Madison Street, Marianna, Florida 32448, for the guardrail project located on Thompson Road.
Description of Work: The scope of work includes the installation of a guardrail on Thompson Road (Bart Rd, West 900 Ft.), to be completed using the method which is identified in the related bid documents.
Pre-bidding questions regarding the project may be addressed to Lynsey Darragh, Procurement Officer, at [email protected].
Bids will be opened and recorded at 2:00 PM CST (or shortly thereafter) on Thursday, May 16, 2024, at the Jackson County Board of County Commissioners Office at 2864 Madison Street, Marianna, FL 32448. Sealed bids can be received at the above address, or electronically via www.centralbidding.com.
Specifications and Contract Documents will be made accessible at www.centralbidding.com, or by contacting Lynsey Darragh, Procurement Officer by email at [email protected].
Board of County Commissioners
By: Paul Donofro, Jr.
BOARD CHAIRMAN
Clayton O. Rooks, III
CLERK OF CIRCUIT COURT
L7269 Dates of Publication: 04/25/2024, 05/02/2024
C-111
TOWN OF MALONE
ADVERTISEMENT FOR BIDS
The Town of Malone (Owner) is requesting Bids for the construction of the following Project:
HURRRICANE MICHAEL BUILDING REPAIRS
(5406 10TH STREET, 5408 10TH STREET, AND 5417 10TH STREET)
FC CDBG-DR M0046
MAL22HR
Bids for the construction of the Project will be received at the Malone Town Hall located at 5182 9th Avenue, Malone, FL 32445 until Thursday, June 6, 2024 at 10:00 AM local time. At that time, or shortly thereafter, the Bids received will be publicly opened and read in the Town Hall Meeting Room.
The Project includes the following Work:
Completion of various interior and exterior renovations to the commercial buildings located at 5406 10th Street, 5408 10th Street, and 5417 10th Street located in downtown Malone, FL. These buildings were heavily damaged by Hurricane Michael. Renovation/Repair activities include but are not limited to; demolition, insulation, painting, ceiling repair, masonry, electrical wiring, lighting, plumbing, HV/AC replacement, flooring, doors, frames, windows and exterior awnings. A complete listing of the project activities and services is included in the project bid documents.
Obtaining the Bidding Documents
The Issuing Office for the Bidding Documents is:
David H. Melvin, Inc.
4428 Lafayette Street, Marianna, Florida 32446
Email request: [email protected]
Office phone: (850) 482-3045
Prospective Bidders may obtain or examine the Bidding Documents at the Issuing Office on Monday through Friday between the hours of 8:00 AM – 4:30 PM and may obtain copies of the Bidding Documents from the Issuing Office as described below. Partial sets of Bidding Documents will not be available from the Issuing Office. Neither Owner nor Engineer will be responsible for full or partial sets of Bidding Documents, including addenda, if any, obtained from sources other than the Issuing Office.
Bidding Documents may be purchased from the Issuing Office during the hours indicated above. Cost does not include shipping charges. Upon Issuing Office’s receipt of payment (non-refundable), printed Bidding Documents or electronic documents will be sent via the prospective Bidder’s delivery service. The shipping charge amount will depend on the shipping method chosen. Bidding Documents are available for purchase in the following formats:
Format:
Bidding Documents (including Full-Size Drawings) – $125.00
Bidding Documents (including Half-Size Drawings) – $100.00
Bidding Documents (Electronic Copies) – No payment required.
Pre-bid Conference
A non-mandatory pre-bid conference for the Project will be held on Monday, May 20, 2024 at 10:00 AM local time at the Town Hall located at 5182 9th Avenue, Malone, FL 32445, an optional site visit is scheduled to follow.
Instructions to Bidders.
For all further requirements regarding bid submittal, qualifications, procedures, and contract award, refer to the Instructions to Bidders that are included in the Bidding Documents.
This Advertisement is issued by:
Owner: Town of Malone
By: Linda Wilson
Title: Town Clerk
Small business and minority businesses, women’s business enterprises, and labor surplus area firms are encouraged to submit proposals, and firms using such subcontractors are strongly encouraged to solicit such firms in the subcontracting process. Any Contracts/subcontracts issued under this procurement must comply with the necessary affirmative steps to assure that minority businesses, women’s business enterprises, and labor surplus area firms are used when possible, in accordance with 2 CFR § 200.321.
EQUAL OPPORTUNITY EMPLOYER HANDICAP ACCESSIBLE/FAIR HOUSING JURISDICTION
L7281 Date of Publication: 05/02/2024
C-111
ADVERTISEMENT FOR BIDS
JACKSON HOSPITAL (Owner) is requesting Bids for the construction of the following Project:
OFFSITE MEDICAL FACILITIES GENERATOR PROJECT
FDEM 4399-099-R
FDEO CDBG-DR M0081
DHM JHO22GE
Bids for the construction of the Project will be received at the office of David H. Melvin, Inc. located at 4428 Lafayette St., Marianna, FL 32446, until Thursday, June 6, 2024 at 2:00 PM local time. At that time, or shortly thereafter, the Bids received will be publicly opened and read at the office of David H. Melvin, Inc., 4428 Lafayette St., Marianna, FL 32446.
The Project includes the following Work:
This project includes the purchase and installation of 9 emergency generators at various locations across the City of Marianna and the Town of Alford. Generator installation to include fuel tank, wiring, automatic transfer switch (ATS), electrical connections, conduits and concrete pad. The generator shall include a wind rated enclosure per Florida Building Code and as specified in the project plans.
Obtaining the Bidding Documents
The Issuing Office for the Bidding Documents is:
DHM Melvin Engineering
4428 Lafayette Street, Marianna, Florida 32446
Email request: [email protected]
Office phone: (850) 482-3045
Prospective Bidders may obtain or examine the Bidding Documents at the Issuing Office on Monday through Friday between the hours of 8:00 AM – 4:30 PM and may obtain copies of the Bidding Documents from the Issuing Office as described below. Partial sets of Bidding Documents will not be available from the Issuing Office. Neither Owner nor Engineer will be responsible for full or partial sets of Bidding Documents, including addenda, if any, obtained from sources other than the Issuing Office.
Bidding Documents may be purchased from the Issuing Office during the hours indicated above. Cost does not include shipping charges. Upon Issuing Office’s receipt of payment (non-refundable), printed Bidding Documents or electronic documents will be sent via the prospective Bidder’s delivery service. The shipping charge amount will depend on the shipping method chosen. Bidding Documents are available for purchase in the following formats:
Format:
Bidding Documents (including Full-Size Drawings) – $125.00
Bidding Documents (including Half-Size Drawings) – $100.00
Bidding Documents (Electronic Copies) – No payment required.
Pre-bid Conference
A non-mandatory pre-bid conference for the Project will be held on Tuesday, May 21, 2024 at 10:00 AM local time at the office of David H. Melvin Engineering located at 4428 Lafayette Street, Marianna, Florida 32446.
Instructions to Bidders.
For all further requirements regarding bid submittal, qualifications, procedures, and contract award, refer to the Instructions to Bidders that are included in the Bidding Documents.
This Advertisement is issued by:
Owner: Jackson Hospital
By: Brooke Donaldson
Title: Chief Executive Officer
Small business and minority businesses, women’s business enterprises, and labor surplus area firms are encouraged to submit proposals, and firms using such subcontractors are strongly encouraged to solicit such firms in the subcontracting process. Any Contracts/subcontracts issued under this procurement must comply with the necessary affirmative steps to assure that minority businesses, women’s business enterprises, and labor surplus area firms are used when possible, in accordance with 2 CFR § 200.321.
EQUAL OPPORTUNITY EMPLOYER HANDICAP ACCESSIBLE/FAIR HOUSING JURISDICTION
L7282 Date of Publication: 05/02/2024
LEGAL NOTICE
NOTICE OF INTENT TO AMEND BOARD POLICIES
The School Board of Jackson County, Florida, gives notice of its intent to amend the following Board Policies: Board Policy 6325
Hard copies of the proposed policies revisions can be reviewed at the Jackson County School Board Office or can be emailed upon request.
Purpose and Effect: The purpose is to update the policies so that they will be consistent with current legislation. The effect is that the policies will be current and consistent with state and federal guidelines.
Authority: 7 C.F.R. 210.21(d); 2 C.F.R. 200.317; 2 C.F.R. 200.318; 2 C.F.R. 200.319; 2 C.F.R. 200.320; 2 C.F.R. 200.321
2 C.F.R. 200.322; 2 C.F.R. 200.323; 2 C.F.R. 200.324; 2 C.F.R. 200.325; 2 C.F.R. 200.326
Any affected person may speak to the proposed policy changes at the Special Board Meeting on Wednesday, May 29, 2024 at 4:30 at the District Office Board Room at 2903 Jefferson Street, Marianna, FL.
The person to be contacted regarding the proposed policy change is:
Aaron Day, Deputy Superintendent
2903 Jefferson Street, Marianna FL 32446
(850)482-1200
[email protected]
Any person with a disability or physical impairment who wishes to attend a meeting and who requires special accommodations should contact the office of the Deputy Superintendent, 850-482-1200, at least 48 hours prior to the meeting.
Cost to agency: Unknown. Cost or benefit to those affected: Unknown. Impact on open market: None. Origination and authorization: Steve R. Benton, Sr., per board approval on Wednesday, May 29, 2024.
DATE: May 29, 2024
TIME: 4:30 P.M. Central Standard Time
PLACE: Board room of the Jackson County School Board,
2903 Jefferson Street, Marianna, FL 32446
THE ENTIRE TEXT OF EACH PROPOSED RULE AND/OR REFERENCED DOCUMENT, AS WELL AS A FULL LISTING OF RELEVANT STATUTES, CAN BE INSPECTED AND/OR COPIES MADE BY THE PUBLIC, DURING OFFICE HOURS, MONDAY THROUGH FRIDAY, AT THE ADDRESS GIVEN ABOVE.
L7274 Date of Publication: 05/02/2024
CONCURRENT NOTICE
NOTICE OF FINDING OF NO SIGNFICANT IMPACT AND
NOTICE OF INTENT TO REQUEST RELEASE OF FUNDS
May 2, 2024
Town of Malone
5182 9th Avenue
Malone, FL 32445
(850) 569-2308
These notices shall satisfy two separate but related procedural requirements for activities to be undertaken by the Town of Malone.
REQUEST FOR RELEASE OF FUNDS
On or about May 21, 2024, the Town of Malone will submit a request to the Florida Department of Commerce (FC) for the release of Community Development Block Grant funds under Title I of the Housing and Community Development (HCD) Act of 1974, as amended, to undertake a project to build a Critical Protection Facility for Town Public Works operations to replace the damaged, substandard pole barn structure currently being used. The building will withstand hurricane force winds and possess enough storage space to sufficiently house heavy equipment, tools, and other essential resources vital for emergency operations and response. The estimated total cost of the project is $1,700,000.00 with $1,700,000.00 in HUD funds; FC agreement #MT142.
FINDING OF NO SIGNIFICANT IMPACT
The Town of Malone has determined that the project will have no significant impact on the human environment. Therefore, an Environmental Impact Statement under the National Environmental Policy Act of 1969 (NEPA) is not required. Additional project information is contained in the Environmental Review Record (ERR) on file at Town of Malone Town Hall, 5182 9th Avenue, and may be examined or copied weekdays 9:00 A.M to 3:00 P.M.
PUBLIC COMMENTS
Any individual, group, or agency may submit written comments on the ERR to the Town of Malone. All comments must be received May 20, 2024. Comments will be considered prior to the Town of Malone requesting a release of funds. Comments should specify which notice they are addressing.
RELEASE OF FUNDS
The Town of Malone certifies to the Florida Department of Commerce and HUD that Greg Ford in his capacity as Town Mayor consents to accept the jurisdiction of the Federal Courts if an action is brought to enforce responsibilities in relation to the environmental review process and that these responsibilities have been satisfied. The State’s approval of the certification satisfies its responsibilities under NEPA and related laws and authorities and allows the Town of Malone to use the CDBG funds.
OBJECTIONS TO RELEASE OF FUNDS
FC will accept objections to its release of funds and the Town of Malone certification for a period of fifteen days following the anticipated submission date or its actual receipt of the request (whichever is later) only if they are on one of the following bases: (a) the certification was not executed by the Certifying Officer of the Town of Malone; (b) the Town of Malone has omitted a step or failed to make a decision or finding required by HUD regulations at 24 CFR part 58; (c) the grant recipient has committed funds or incurred costs not authorized by 24 CFR Part 58 before approval of a release of funds by the State; or (d) another Federal agency acting pursuant to 40 CFR Part 1504 has submitted a written finding that the project is unsatisfactory from the standpoint of environmental quality. Objections must be prepared and submitted in accordance with the required procedures at 24 CFR Part 58, Sec. 58.76 and shall be addressed to the Florida Department of Commerce, CDBG Program, MSC-400, 107 East Madison Street, Tallahassee, FL 32399-6508. Potential objectors should contact the Town of Malone to verify the actual last day of the objection period.
Greg Ford, Town Mayor
L7277 Date of Publication: 05/02/2024
NOTICE OF SALE PURSUANT
Notice is given pursuant of the Self Storage Facility Act, Florida Statutes Chapter 83, Part IV, that Safe Storage, a self-storage facility will sell by auction, May 6, 2024, to the highest bidder the contents of spaces noted to the following lessees:
• Mary Walden
• Bridget Jenkins
• Michael Swearingen
Safe Storage has the right to accept and reject any bids. Spaces contain a variety of household items, personal property and furniture. Bids only accepted at storagetreasures. com. Auction will begin online at 10:00 a.m., May 6, 2024. The units are located at Safe Storage 5053 Highway 90, Marianna FL 32446.
L7264
Dates of Publication: 04/25/2024, 05/02/2024
TRI-COUNTY COMMUNITY COUNCIL, INC.
302 North Oklahoma Street; Bonifay, FL 32425
Due to on-going COVID-19 concerns, Tri-County Community Council, Inc., Board of Directors will meet via hybrid format at 5:00 p.m. on Thursday, May 9, 2024 at the Life Enrichment Senior Center located at 312 College Avenue, DeFuniak Springs, FL 32435. The hybrid meeting will allow for in-person or online attendance. A Finance meeting will be held at 4:15. For more information, please call 1-800-395-2696.
L7278
Date of Publication: 05/02/2024
NOTICE OF PUBLIC SALE:
H & H ENTERPRISES gives notice that on 06/10/2024 at 10:00 AM the following vehicles(s) may be sold by public sale at 4421 JACKSON ST MARIANNA, FL 32448 to satisfy the lien for the amount owed on each vehicle for any recovery, towing, or storage services charges and administrative fees allowed pursuant to Florida statute 713.78.
1N4BL4CV8RN387384
2024 NISS
L7279
Date of Publication: 05/02/2024
Notice Under Fictitious Name Law Pursuant to Section 865.09, Florida Statutes
NOTICE IS HEREBY GIVEN that the undersigned, desiring to engage in business under the fictitious name of Biggie Bouncers: Located at 5878 Shermanites Rd: Jackson County in the City of Greenwood: Florida, 32443 intends to register the said name with the Division of Corporations of the Florida Department of State,Tallahassee, FL and/or Clerk of the Circuit Court of Jackson County, FL.
L7273
Date of Publication: 05/02/2024
Notice Under Fictitious Name Law Pursuant to Section 865.09, Florida Statutes
NOTICE IS HEREBY GIVEN that the undersigned, desiring to engage in business under the fictitious name of Jaxon Arms: Located at 4991 Land Drive: Jackson County in the City of Marianna: Florida, 32448 intends to register the said name with the Division of Corporations of the Florida Department of State,Tallahassee, FL and/or Clerk of the Circuit Court of Jackson County, FL.
L7283
Date of Publication: 05/02/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
2410 OF 2021
NOTICE IS HEREBY GIVEN THAT: SAMMIE D. SIMMONS or DONNA G SIMMONS the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
2410 OF 2021
Parcel ID:
06-2N-11-0000-0050-0230
Name in which Assessed
MORRIS K FORD III
MARGARET F BARNWELL
DEBORAH F WILLIAMS
Description of Property:
A LOT OR PARCEL OF LAND IN JACKSON COUNTY, FLORIDA AND BEING MORE PARTICULARLY DESCRIBED AS FOLLOWS: BEGINNING AT THE NORTHEAST CORNER OF THE NORTHWEST QUARTER OF THE SOUTHEAST QUARTER OF SECTION 6, T2N, R11W, AND THENCE SOUTH 88 DEGREES-18 MINUTES -58 SECONDS WEST ALONG THE NORTH LINE OF SAID FORTY, 948.81 FEET TO THE EASTERLY SIDE OF AN UNPAVED COUNTY ROAD; THENCE SOUTH 17 DEGREES -36 MINUTES 30 SECONDS WEST ALONG THE EASTERLY SIDE OF SAID ROAD, 695.8 FEET TO THE SOUTH LINE OF THE NORTH HALF OF SAID FORTY; THENCE NORTH 87 DEGREES -52 MINUTES -47 SECONDS EAST ALONG THE SOUTH LINE OF SAID TWENTY, 1180 FEET TO THE EAST LINE OF SAID FORTY; THENCE NORTH 1 DEGREES -55 MINUTES -45 SECONDS WEST ALONG THE EAST LINE OF SAID FORTY, 648.27 FEET TO THE POINT OF BEGINNING. SAID PARCEL BEING IN THE NORTHWEST QUARTER OF THE SOUTHEAST QUARTER OF SECTION 6, T2N, R11W AND CONTAINING 15.948 ACRES, MORE OR LESS.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7244
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
1123 OF 2019
NOTICE IS HEREBY GIVEN THAT: BUFFALO BILL, LLC the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
1123 OF 2019
Parcel ID:
04-4N-10-0343-0000-0115
Name in which Assessed
DAFFIN MERCANTILE CO INC
Description of Property:
COMMENCE AT THE NORTHWEST CORNER OF SECTION 4, TOWNSHIP 4 NORTH, RANGE 10 WEST, JACKSON COUNTY, FLORIDA, AS PER DEPARTMENT OF TRANSPORTATION RIGHT OF WAY PLANS, THENCE SOUTH 03 DEGREES 12 MINUTES 17 SECONDS EAST 646.0 FEET TO THE CENTER LINE OF SURVEY OF STATE ROAD 10, THENCE SOUTH 67 DEGREES 52 MINUTES 47 SECONDS EAST 242.62 FEET, THENCE SOUTH 79 DEGREES 35 MINUTES 47 SECONDS EAST 768.11 FEET, THENCE SOUTH 58 DEGREES 34 MINUTES 47 SECONDS EAST 2044.81 FEET, THENCE SOUTH 33 DEGREES 04 MINUTES 47 SECONDS EAST 783.12 FEET, THENCE SOUTH 71 DEGREES 55 MINUTES 35 SECONDS EAST 1444.64 FEET TO DEPARTMENT OF TRANSPORTATION STATION NO. 23 + 98.90, THENCE SOUTH 16 DEGREES 23 MINUTES 25 SECONDS EAST 26.69 FEET TO THE NORTHEAST CORNER OF LOT #11 OF THE PITTMAN ADDITION TO MARIANNA, FLORIDA, THENCE SOUTH 16 DEGREES 04 MINUTES 51 SECONDS WEST 250.0 FEET TO A CONCRETE MARKER AND CALL THIS THE POINT OF BEGINNING, THENCE NORTH 72 DEGREES 13 MINUTES 35 SECONDS WEST 97.17 FEET TO AN IRON PIPE, THENCE SOUTH 19 DEGREES 52 MINUTES 17 SECONDS WEST 209.02 FEET TO A CONCRETE MARKER, THENCE SOUTH 19 DEGREES 44 MINUTES 47 SECONDS WEST 80.0 FEET TO IRON PIPE., THENCE SOUTH S9 DEGREES 25 MINUTES, 30 SECONDS EAST 118.9 FEET THENCE NORTH 16 DEGREES 04 MINUTES 51 SECONDS EAST 313.06 FEET TO THE POINT OF BEGINNING.
THIS TRACT IS LOCATED WITHIN THE CITY LIMITS OF MARIANNA, FLORIDA, AND WITHIN THE SOUTHEAST QUARTER OF SECTION 4, TOWNSHIP 4 NORTH, RANGE 10 WEST, JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7249
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
2294 OF 2020
NOTICE IS HEREBY GIVEN THAT: CLAUDIUS KESSLER the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
2294 OF 2020
Parcel ID:
02-2N-11-0087-1270-0370
Name in which Assessed
D W MATTHEWS
OPAL D MATTHEWS
Description of Property:
LOT 37, BLOCK 127, COMPASS LAKE HILLS, UNIT FIVE, ACCORDING TO THE MAP OR PLAT THEREOF, RECORDED IN PLAT BOOK A-4, PAGE 130 THROUGH 140, INCLUSIVE, PUBLIC RECORDS OF JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7242
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
2269 OF 2020
NOTICE IS HEREBY GIVEN THAT: CLAUDIUS KESSLER the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
2269 OF 2020
Parcel ID:
02-2N-11-0087-1200-0160
Name in which Assessed
JOSE BELTRAN BERMUDEZ CAMPOS
Description of Property:
LOT 16, BLOCK 120, COMPASS LAKE HILLS, UNIT FIVE, ACCORDING TO THE MAP OR PLAT THEREOF, RECORDED IN PLAT BOOK A-4, PAGE 130 THROUGH 140, INCLUSIVE, PUBLIC RECORDS OF JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7241
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
TOWN OF GRAND RIDGE
REQUEST FOR SUBMITTALS
CDBG Grant Administration
for a CDBG-MIT Funded Project
Grant Agreement # MT147
RFP # 2024-MT147ADMIN
Town of Grand Ridge invites Qualified individuals/firms to submit to the TOWN OF GRAND RIDGE, PROPOSALS FOR GRANT ADMINISTRATION SERVICES RELATED TO CDBG-MIT GRANT AGREEMENT # MT147 FUNDING THROUGH THE FLORIDA DEPARTMENT OF COMMERCE, RFP NO: 2024-MT147ADMIN
All submittals will be ranked separately and considered on an equally competitive basis.
Ranking criteria and requirements may be requested in person by contacting Amanda Applewhite, Town Clerk at 2086 Porter Ave, Grand Ridge, FL 32442 or by email at [email protected]
Responses will be due no later than 2:00 P.M CST – March 31, 2024, submitted to the Town of Grand Ridge, ATTN: Amanda Applewhite, 2086 Porter Ave, Grand Ridge, FL 32442.
Small business and minority businesses, women’s business enterprises, and labor surplus area firms are encouraged to submit proposals, and firms using such subcontractors are strongly encouraged to solicit such firms in the subcontracting process. Any Contracts/subcontracts issued under this procurement must comply with the necessary affirmative steps to assure that minority businesses, women’s business enterprises, and labor surplus area firms are used, when possible, in accordance with 2 CFR § 200.321
EQUAL OPPORTUNITY EMPLOYER HANDICAP ACCESSIBLE/FAIR HOUSING JURISDICTION
L7275 Dates of Publication: 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO. 635 OF 2021
NOTICE IS HEREBY GIVEN THAT: SAMMIE D SIMMONS or DONNA G SIMMONS the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
635 OF 2021
Parcel ID:
23-5N-09-0000-0130-0030
Name in which Assessed
ROBERT NICHOLAS MATTHEWS
Description of Property:
BEGIN AT SOUTHEAST CORNER OF THE NORTH HALF OF SOUTHEAST QUARTER, SECTION 23, TOWNSHIP 5 NORTH, RANGE 9 WEST, THENCE WEST 1,767 FEET TO THE SOUTHEAST CORNER OF THE LAND DEEDED TO GUY LEE BRYANT BY DEED RECORDED IN OR BOOK 65, PAGE 137, THENCE NORTH 467 FEET, THENCE WEST 123 FEET TO POINT OF BEGINNING, THENCE WEST 811 FEET TO THE WEST LINE OF SAID NORTH ONE HALF OF SOUTHEAST ONE QUARTER, THENCE NORTH 853 FEET, THENCE EAST 811 FEET, THENCE SOUTH 853 FEET TO POINT OF BEGINNING.
ALSO: BEGINNING AT THE SOUTHWEST CORNER OF THE NORTHWEST ONE QUARTER OF THE SOUTHEAST ONE QUARTER OF SECTION 23, TOWNSHIP 5 NORTH, RANGE 9 WEST AND RUN THENCE EAST 467 FEET TO THE POINT OF BEGINNING; THENCE RUN NORTH 467 FEET; THENCE EAST 467 FEET; THENCE SOUTH 467 FEET; THENCE WEST 467 FEET.
ALSO: BEGINNING AT THE SOUTHWEST CORNER OF THE NORTHWEST ONE QUARTER OF THE SOUTHEAST ONE QUARTER OF SECTION 23, TOWNSHIP 5 NORTH, RANGE 9 WEST, AND RUN THENCE NORTH 467 FEET; THENCE EAST 467 FEET; THENCE SOUTH 467 FEET; THENCE WEST 467 FEET TO THE POINT OF BEGINNING ALL BEING IN JACKSON COUNTY, FLORIDA.
LESS AND EXCEPT THE FOLLOWING DESCRIBED PROPERTY: COMMENCE AT THE SOUTHEAST CORNER OF NORTH ONE HALF OF THE SOUTHEAST ONE QUARTER OF SECTION 23, TOWNSHIP 5 NORTH, RANGE 9 WEST, AND RUN WEST 1890.0 FEET, THENCE RUN NORTH 467.0 FEET TO AN IRON PIPE, THE POINT OF BEGINNING. THENCE RUN NORTH 853.0 FEET TO A CONCRETE MONUMENT, THENCE RUN WEST 324.0 FEET TO A CONCRETE MONUMENT, THENCE RUN SOUTH 853.0 FEET TO AN IRON PIPE, THENCE RUN EAST 324.0 FEET TO THE P.O.B. LYING AND BEING IN THE NORTH ONE HALF OF THE SOUTHEAST ONE QUARTER OF SAID SECTION, JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7240
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
2435 OF 2020
NOTICE IS HEREBY GIVEN THAT: CLAUDIUS KESSLER the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
2435 OF 2020
Parcel ID:
02-2N-11-0087-1520-0550
Name in which Assessed
JOSEPH PASERCHIA
Description of Property:
LOT 55, BLOCK 152, COMPASS LAKE HILLS, UNIT FIVE, ACCORDING TO THE MAP OR PLAT THEREOF, RECORDED IN PLAT BOOK A-4, PAGE 130 THROUGH 140, INCLUSIVE, PUBLIC RECORDS OF JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7247
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
2419 OF 2020
NOTICE IS HEREBY GIVEN THAT: CLAUDIUS KESSLER the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
2419 OF 2020
Parcel ID:
02-2N-11-0087-1500-0200
Name in which Assessed
KATY BLAIR
ROBBIE BLAIR
Description of Property:
LOT 20, BLOCK 150, COMPASS LAKE HILLS, UNIT FIVE, ACCORDING TO THE MAP OR PLAT THEREOF, RECORDED IN PLAT BOOK A-4, PAGE 130 THROUGH 140, INCLUSIVE, PUBLIC RECORDS OF JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7246
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
2307 OF 2020
NOTICE IS HEREBY GIVEN THAT: CLAUDIUS KESSLER the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
2307 OF 2020
Parcel ID:
02-2N-11-0087-1300-0230
Name in which Assessed
LINDA S BARNES
C LELAND BARNES
Description of Property:
LOT 23, BLOCK 130, COMPASS LAKE HILLS, UNIT FIVE, ACCORDING TO THE MAP OR PLAT THEREOF, RECORDED IN PLAT BOOK A-4, PAGE 130 THROUGH 140, INCLUSIVE, PUBLIC RECORDS OF JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7243
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
2413 OF 2020
NOTICE IS HEREBY GIVEN THAT: CLAUDIUS KESSLER the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
2413 OF 2020
Parcel ID:
02-2N-11-0087-1490-0050
Name in which Assessed
JANE ANN HUTER
Description of Property:
LOT 5, BLOCK 149, COMPASS LAKE HILLS, UNIT FIVE, ACCORDING TO THE MAP OR PLAT THEREOF, RECORDED IN PLAT BOOK A-4, PAGE 130 THROUGH 140, INCLUSIVE, PUBLIC RECORDS OF JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7245
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
TOWN OF GRAND RIDGE
REQUEST FOR SUBMITTALS
CDBG Engineering Services
for a CDBG-MIT Funded Project
Grant Agreement # MT147
RFQ # 2024-MT147ENG
Town of Grand Ridge invites Qualified individuals/firms to submit to the TOWN OF GRAND RIDGE, STATEMENTS OF QUALIFICATIONS FOR ENGINEERING SERVICES RELATED TO CDBG-MIT GRANT AGREEMENT # MT147 FUNDING THROUGH THE FLORIDA DEPARTMENT OF COMMERCE, RFQ NO: 2024-MT147ENG,
All submittals will be ranked separately and considered on an equally competitive basis.
Ranking criteria and requirements may be requested in person by contacting Amanda Applewhite, Town Clerk at 2086 Porter Ave, Grand Ridge, FL 32442 or by email at [email protected]
Responses will be due no later than 2:00 P.M CST – March 31, 2024, submitted to the Town of Grand Ridge, ATTN: Amanda Applewhite, 2086 Porter Ave, Grand Ridge, FL 32442.
Small business and minority businesses, women’s business enterprises, and labor surplus area firms are encouraged to submit proposals, and firms using such subcontractors are strongly encouraged to solicit such firms in the subcontracting process. Any Contracts/subcontracts issued under this procurement must comply with the necessary affirmative steps to assure that minority businesses, women’s business enterprises, and labor surplus area firms are used, when possible, in accordance with 2 CFR § 200.321
EQUAL OPPORTUNITY EMPLOYER HANDICAP ACCESSIBLE/FAIR HOUSING JURISDICTION
L7276 Dates of Publication: 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
448 OF 2021
NOTICE IS HEREBY GIVEN THAT: SAMMIE D. SIMMONS or DONNA G. SIMMONS the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
448 OF 2021
Parcel ID:
07-2N-09-0000-0070-0050
Name in which Assessed
EVELYN BOGGS FREE
Description of Property:
COMMENCE AT SOUTHWEST CORNER OF SOUTHWEST QUARTER OF SECTION 7, TOWNSHIP 2 NORTH, RANGE 9 WEST AND RUN NORTH 880 FEET FOR THE POINT OF BEGINNING; THENCE RUN NORTH 220 FEET; THENCE RUN EAST 2640 FEET TO THE EAST SIDE OF SOUTHWEST QUARTER OF SECTION 7, TOWNSHIP 2 NORTH, RANGE 9 WEST; THENCE RUN SOUTH 220 FEET; THENCE RUN WEST 2640 FEET TO THE POINT OF BEGINNING. CONTAINING 13.33 ACRES MORE OR LESS.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7248
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
1584 OF 2017
NOTICE IS HEREBY GIVEN THAT: MICHAEL J GRAZIOSO the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
1584 OF 2017
Parcel ID:
02-2N-11-0083-10AB-0050
Name in which Assessed
RONALD ROBENOLT
Description of Property:
LOT 5, BLOCK AB, CORRECTED PLAT OF COMPASS LAKE HILLS UNIT TWO, ACCORDING TO THE PLAT THEREOF, AS RECORDED IN PLAT BOOK A-4, PAGES 111A THROUGH 115A, INCLUSIVE, OF THE PUBLIC RECORDS OF JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7250
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT IN AND FOR JACKSON COUNTY, FLORIDA
CASE NO. 24-CA-051
QUALITY CARE SERVICES OF NW FL, LLC
Plaintiff,
vs.
MAUDE REBECCA PLEDGER, JESSIE CORE, MYRTHEL JUANITA BOGGS, all if alive, or if deceased, their unknown spouse, heirs, devisees, grantees, judgment creditors, and all other parties claiming by, through, under or against the aforementioned defendants; the unknown spouse, heirs, devisees, grantees and judgment creditors of aforementioned defendants, and all other parties claiming by, through under or against the aforementioned defendants; and all unknown natural persons, if alive, and if dead or not known to be dead or alive, their several and respective unknown spouses, heirs, devisees, grantees and judgment creditors, or other parties claiming by, through, under or against those unknown natural persons; and the several and respective unknown assigns, successors in interest, trustees, or any other person claiming by, through, under or against any corporation or other legal entity named as a defendant; and all claimants, persons or parties, natural or corporate, or whose exact legal status is unknown, claiming under any of the above named or described defendants or parties claiming to have any right, title or interest in the property described in this complaint, JOHN LOWELL CORE and KATHERINE R. MORALES,
Defendants.
____________________________________________/
NOTICE OF ACTION
TO: Any unknown spouse, and all heirs, devisees, grantees, judgment creditors, and all other parties claiming by, through, under or against MAUDE REBECCA PLEDGER and/or JESSIE P. CORE; and all other parties claiming by, through under or against them; and all unknown natural persons, if alive, and if dead or not known to be dead or alive, their several and respective unknown spouses, heirs, devisees, grantees and judgment creditors, or other parties claiming by, through, under or against those unknown natural persons; and the several and respective unknown assigns, successors in interest, trustees, or any other person claiming by, through, under or against any corporation or other legal entity named as a defendant; and all claimants, persons or parties, natural or corporate, or whose exact legal status is unknown, claiming under MAUDE REBECCA PLEDGER and/or JESSIE P. CORE, or parties claiming to have any right, title or interest in the property described in this complaint.
YOU ARE NOTIFIED that a Complaint to Quiet Title has been filed against you by Quality Care Services of NW FL, LLC and you are required to serve a copy of your written defenses to it, if any, on A. Clay Milton, Esq., Petitioner’s Attorney, whose address is Post Office Box 1508, Marianna, Florida 32447, on or before May 20, 2024. You must file the original of your written defenses with the Clerk of the Circuit Court, Jackson County Courthouse, at Post Office Drawer 510, Marianna, Florida 32447 or by hand delivery to 4445 Lafayette Street, Marianna, Florida 32446, either before service on Plaintiff’s attorney or immediately after service. Otherwise, a default will be entered against you for the relief demanded in the petition.
DATED this the 17th day of April, 2024.
CLAYTON O. ROOKS, III, Clerk
Jackson County, Florida
BY: /s/ Abigail Perkins
As Deputy Clerk
L7263
Dates of Publication: 04/25/2024, 05/02/2024, 05/09/2024, 05/16/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
2452 OF 2021
NOTICE IS HEREBY GIVEN THAT: MICHAEL J JOHNSON, RESULTS DRIVEN, LLC the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
2452 OF 2021
Parcel ID:
14-3N-11-0000-0110-0010
Name in which Assessed
PAMELA S MEDLOCK BOUTWELL ESTATE
Description of Property:
THE SOUTH HALF OF THE EAST HALF OF THE NORTH HALF OF THE SOUTHEAST QUARTER OF THE SOUTHWEST QUARTER, IN SECTION 14, TOWNSHIP 3 NORTH, RANGE 11 WEST, JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7252
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
2581 OF 2021
NOTICE IS HEREBY GIVEN THAT: SAMMIE D SIMMONS or DONNA G SIMMONS the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
2581 OF 2021
Parcel ID:
28-5N-11-0000-0020-0000
Name in which Assessed
BESSIE DAVIS ESTATE
MARY RUSS
LLOYD WHITE JR ESTATE
HUBIE WHITE ESTATE
PLUET WHITE ESTATE
OCEE WHITE DIXON ESTATE
MENEFEE WHITE ESTATE
VERNON DAVIS JR
DANA SHINE
TENA WORRELL
BETTY JONES
GLADYS DANIELS
JELMER ZIMMERMAN
JAVIER ZIMMERMAN
Description of Property:
NORTHWEST QUARTER OF NORTHEAST QUARTER OF SECTION 28, TOWNSHIP 5 NORTH, RANGE 11 WEST, JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7253
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
REQUEST FOR PROPOSALS
JACKSON COUNTY
Sealed proposals will be accepted by the Jackson County Board of County Commissioners at the Purchasing Office located at the Jackson County Administration building, 2864 Madison Street, Marianna, FL 32448 until 2:00 pm CST on Thursday, May 23, 2024, for the following project:
PROJECT NUMBER: 2324-20
PROJECT NAME: (Rebid) Great Oaks Concessionaire
SUBMISSION DEADLINE: May 23, 2024 by 2:00 pm CST
SUBMISSION OPENING: Proposals will be opened and recorded by the Purchasing Office of the Jackson County Board of County Commissioners located at 2864 MADISON STREET, Marianna, Florida 32448 on Thursday, May 23, 2024, at 2:00pm, or shortly thereafter.
Specifications and official RFP Documents can be accessed online at Central Bidding (www.centralbidding.com). For questions related to the electronic bidding process, please call Central Bidding at 225-810-4814. Electronic Proposals may be submitted at Central Bidding (www.centralbidding.com). Questions regarding the specifications or RFP should be directed to Lynsey Darragh, Procurement Officer by email at [email protected]
List of bidders and awards (if any) shall be announced at a meeting of the Jackson County Board of County Commissioners. Bid award will be made to the best bidder, but the right is reserved to reject any or all bids.
Board of County Commissioners
By: Paul Donofro, Jr. BOARD CHAIRMAN
Clayton. O. Rooks
CLERK OF CIRCUIT COURT
L7284
Dates of Publication: 05/02/2024, 05/09/2024
REQUEST FOR QUALIFICATIONS
JACKSON COUNTY
Sealed bids will be accepted by the Jackson County Board of County Commissioners at the Purchasing Office located at the Jackson County Administration building, 2864 Madison Street, Marianna, FL 32448 until 2:00 pm CST on Thursday, May 23, 2024, for the following project:
BID NUMBER: 2324-27
BID NAME: TDC Strategic Plan
SUBMISSION DEADLINE: May 23, 2024 by 2:00 pm CST
BID OPENING: Bids will be opened and recorded by the Purchasing Office of the Jackson County Board of County Commissioners located at 2864 MADISON STREET, Marianna, Florida 32448 on Thursday, May 23, 2024 at 2:00pm, or shortly thereafter.
Specifications and official RFQ Documents can be accessed online at Central Bidding (www.centralbidding.com). For questions related to the electronic bidding process, please call Central Bidding at 225-810-4814. Electronic Bids may be submitted at Central Bidding (www.centralbidding.com). Questions regarding the specifications or RFQ should be directed to Lynsey Darragh, Procurement Officer by email at [email protected]
List of bidders and awards (if any) shall be announced at a meeting of the Jackson County Board of County Commissioners. Bid award will be made to the best bidder, but the right is reserved to reject any or all bids.
Board of County Commissioners
By: Paul Donofro, Jr. BOARD CHAIRMAN
Clayton. O. Rooks
CLERK OF CIRCUIT COURT
L7285
Dates of Publication: 05/02/2024, 05/09/2024
IN THE COUNTY COURT OF THE FOURTEENTH JUDICIAL CIRCUIT IN AND FOR JACKSON COUNTY, FLORIDA
CASE NUMBER: 24-130 CC
JAMES C. MAYO and MARGARET H. MAYO,
Plaintiffs,
vs.
JASON GALLIHUGH, if alive, or if deceased, his unknown spouse, heirs, devisees, grantees, judgment creditors, and all other parties claiming by, through, under or against him; the unknown spouse, heirs, devisees, grantees and judgment creditors of defendant, and all other parties claiming by, through under or against defendant; and all unknown natural persons, if alive, and if dead or not known to be dead or alive, their several and respective unknown spouses, heirs, devisees, grantees and judgment creditors, or other parties claiming by, through, under or against those unknown natural persons; and the several and respective unknown assigns, successors in interest, trustees, or any other person claiming by, through, under or against any corporation or other legal entity named as a defendant; and all claimants, persons or parties, natural or corporate, or whose exact legal status is unknown, claiming under any of the above named or described defendants or parties claiming to have any right, title or interest in the property described in this complaint, TRISTON GALLIHUGH, and MACKENZIE O’BRYAN, UNKNOWN TENANT #1 and UNKNOWN TENANT #2 Located at 1761 Alabama Street, Alford, Florida,
Defendants.
____________________________________________/
NOTICE OF ACTION
TO: JASON GALLIHUGH, deceased, his unknown spouse, heirs, devisees, grantees, judgment creditors, and all other parties claiming by, through, under or against him; the unknown spouse, heirs, devisees, grantees and judgment creditors of defendant, and all other parties claiming by, through under or against defendant; and all unknown natural persons, if alive, and if dead or not known to be dead or alive, their several and respective unknown spouses, heirs, devisees, grantees and judgment creditors, or other parties claiming by, through, under or against those unknown natural persons; and the several and respective unknown assigns, successors in interest, trustees, or any other person claiming by, through, under or against any corporation or other legal entity named as a defendant; and all claimants, persons or parties, natural or corporate, or whose exact legal status is unknown, claiming under any of the above named or described defendants or parties claiming to have any right, title or interest in the property described in this complaint,
TRISTON GALLIHUGH,
AND ALL OTHERS WHOM IT MAY CONCERN
YOU ARE HEREBY NOTIFIED that a Complaint to Foreclose Assessment Lien on the following described property has been filed against you by JAMES C. MAYO and MARGARET H. MAYO:
Lots 9 and 10 in Block 14 in the Town of Alford, Florida, as per plat of said Town recorded in Plat Cabinet(s), Page 156, in the Clerk’s Office in Marianna, Florida, and being a part of Section 1, Township 3 North, Range 12 West.
Also, that portion of the abandoned alley West of the Bay Line Railroad in Ward II, Section 1, Township 3 North, Range 12 West. Said Alley was abandoned by the Town of Alford, Florida and described as follows: Beginning at the Southwest corner of Lewis H. Cutchins property, Block 14, Lots 9 and 10, Section 1, Township 3 North, Range 12 West, extending 10 feet West and 60 feet North, thence extending 10 feet East to Northwest corner, thence 60 feet South to Point of Beginning. PARCEL ID# 01-3N-12-0004-0140-0090
You are required to serve a copy of your written defenses to it, if any, on A. Clay Milton, Esq., Plaintiffs’ Attorney, whose address is Post Office Box 1508, Marianna, Florida 32447, on or before May 7, 2024. You must file the original of your written defenses with the Clerk of the Circuit Court, Jackson County Courthouse, Marianna, Florida 32446, either before service on petitioner’s attorney or immediately after service. Otherwise, a default will be entered against you for the relief demanded in the Complaint.
DATED this the 17th day of April, 2024.
CLAYTON O. ROOKS, III, Clerk
Jackson County, Florida
BY: /s/ Abigail Perkins
As Deputy Clerk
L7262
Dates of Publication: 04/25/2024, 05/02/2024, 05/09/2024, 05/16/2024
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT, IN AND FOR JACKSON COUNTY, FLORIDA
JUSTIN HOULISTON and LORRAINE HOULISTON,
Plaintiff
Vs.
WILLIAM GRIMSLEY, JR., and MARYANNE GRIMSLEY, 7911 Thomas Drive, Suite 2, Panama City Beach, Florida 3408 750 PROPERTY CORP, 750 West 84th Street Hialeah, Florida 33014, CWYNAR JANUSZ and JOANNE G. MacDONALD, 4410 AlA Unit #110, Vero Beach, Florida 32963, COMIAN X2 TAX LIEN FUND, LLC, 700 Route 130 North, Suite 101 Cinnaminson, NJ 08077 COMPASS LAKE IN THE HILLS PROPERTY OWNER ASSOCIATION, INC., 645 Compass Lake Drive, Alford, Florida 32420, DANIEL G. ZEIGLER, 1251 Fairland Road, Lehighton, PA 18235, CARL FRITTS, 696 Burrage Road NE, Concord, NC 28025 JOSE ANDRADA and LILLYBETH ANDRADA, 525 Cover Bridge Road, Eglin Illinois 60125 HARLAND. BECK and ANNA M. PIETERSZ, 8215 SW 87th Terrace, Miami, Florida 33143 LARRY CARNLEY, MICHAEL RIGANO and JUDITH RIGANO, 58 Steinberg Avenue, Garfield, NJ 07026 VICTOR Z. SZYMANSKI, 239 Mariners Mark Way Apt. 202, Virginia Beach, VA 23451, WAYNE M. J. FRASER, 2331 N. State Rd. 7, Suite 201 Lauderdale Lakes, Florida 33313MICHAEL JOHN DRESLIN, 4366 Gravely Meadow Ct., Haymarket, VA 20169 ERIC FEENSTRA and CYNTHIA FEENSTRA, 861 South West 72nd Ave, Plantation, Fl 33317 MARGARETH PAULTRE, 225 Trotters Run, Macon, GA 31210 ROBERTS. BLANKET and CINDY BLANKET, 4441 Stirling Rd., Ft. Lauderdale, Fl 33314 WP RE VENTURES 1, LLC, 166 W. Washington St. Suite730 Chicago, IL 60602 and EDWARD HOTYCKEY And EEVI HOTYCKEY
Defendant.
____________________________________________/
NOTICE OF ACTION
TO: WILLIAM GRIMSLEY JR., and MARYANNE GRIMSLEY, 750 PROPERTY CORP., CWYNAR JANUSZ and JOANNE G. MacDONALD, COMIAN x2 TAX LIEN FUND, LLC, COMPASS LAKE IN THE HILLS PROPERTY OWNERS ASSOCIATION, INC.,DANIEL G. ZEIGLER, CARL FRITTS, JOSE ANDRADA and LILLYBETH ANDRADA, HARLAND. BECK and ANNA M. PIETERSZ, LARRY CARNLEY, MICHAEL RIGANO and JUDITH RIGANO, VICTOR Z. SZYMANSKI, WAYNE J. M. FRASER, MICHAEL JOHN DRESLIN, ERIC FEENSTRA and CYNTHIA FEENSTRA, MARGARETH PAULTRE, ROBERTS. BLANKET and CIDNY BLANKET, WP RE VENTURES 1, LLC, and EDWARD HOTYCKEY and EEVI HOTYCKEY and all other parties claiming by, through, under or against them, and all unknown natural persons if alive, and if dead or not known to be dead or alive, their several and respective spouse, heirs, devisees, grantees and creditors, or other parties claiming by, through or under those unknown natural persons; and, the several and respective unknown assigns, successors in interest, trustees or any other person claiming by, through, under or against any corporation or other legal entity named as a defendant and all claimants, persons or parties, natural or corporate, or whose exact legal status is unknown, claiming under any of the above-named defendants or parties or claiming under any of the above named or defendants hereafter described.
YOU ARE HEREBY NOTIFIED that a Complaint on the following described property:
Th North Half of North Half of Section 10, Township 2 North, Range 11 West, Jackson County, Florida, less and except any portion lying within The right-of-way of State Road S-167.
You are required to serve a copy of your written defenses, if any, to H. Guy Green, Attorney for Plaintiff, 4387 Clinton Street, Marianna, Florida 32446 on or before June 3, 2024 and file the original with the Clerk of Circuit Court in Jackson County, Florida, 4445 Lafayette Street, Marianna, Florida 32446; otherwise a default will be entered against you for the relief prayed for in the Complaint.
This notice shall be published once a week for four consecutive weeks in the Jackson County Times.
WITNESS my hand and seal of said court at Marianna, Jackson County, Florida on this 22nd day of April 2024.
CLERK OF CIRCUIT COURT
By: Marissa Drigger
Deputy Clerk
H. Guy Green
4387 Clinton Street
Marianna, Florida 32446
850/526-3707-Telephone
850/526-5810-Facsimile
Florida Bar No.: 153300
L7280
Dates of Publication: 05/02/2024, 05/09/2024, 05/16/2024, 05/23/2024
