CITY OF COTTONDALE REQUESTED FOR BIDS FOR
FOR APPRAISALS AND REVIEW APPRAISALS SERVICES REQUIRED TO CARRY OUT THE CDBG-CV PROGRAM GRANT #22CV-S15 REQUEST FOR BIDS 2024-02
The City of Cottondale, Florida invites qualified firms to submit a bid for Appraisal and a bid for Review Appraisal Services related to a Corona Virus Community Development Block Grant (CDBG-CV) Project Number 22CV-S15 for the renovation and expansion of the City of Cottondale Community Center.
The CITY OF COTTONDALE, FLORIDA anticipates the acquisition of a parcel of vacant property identified by the Jackson County Property Appraiser as parcel #31-5N-11-0089-00R0-0050 with a street address of 2662 Front Street, Cottondale, Florida. The property the City anticipates acquiring will be utilized as additional off-street parking for the City of Cottondale Community Center located at 2666 Front Street, Cottondale, Florida. The City of Cottondale, Florida is requesting bids for appraisal and review appraisal services required for the acquisition of the property funded by the City of Cottondale’s Community Development Block Grant Corona Virus (CDBG-CV) Project (#22CV-S15), awarded by the FloridaCommerce Department.
The acquisition process requires that an appraisal and a separate review appraisal of the above referenced parcel of land be completed. All work shall be in conformance with the requirements of the CDBG-CV grant program. Bidders must meet all CDBG/COM requirements. Additionally, the appraisal and review appraisal of the property planned for acquisition must adhere to the requirements of the Uniform Relocation Assistance and Real Property Acquisition Policies Act of 1970, as amended, and (42 U.S.C. 4201-4655) and implementing regulations at 49 CFR part 24.
Bids are invited upon the items and quantities of work as follows:
The Jackson County Property Appraiser’s parcel number, and property address, are outlined in the scope of work above and bid spreadsheet.
The City of Cottondale reserves the right to reject any or all bids or to waive any informality in the review of bids received.
For more information, please contact Ms. Sherri McBride, Cottondale City Clerk located at 2659 Front Street, Cottondale, FL 32431, by phone at (850) 352-4361 or by email at [email protected].
Bids will be due by Tuesday, May 07, 2024 at 12 PM Noon CST. Bids shall be submitted to the City of Cottondale, ATTN: Sherri McBride, City Clerk, PO Box 398; 2659 Front Street, Cottondale, FL 32431.
The City of Cottondale is an Equal Opportunity Employer, a Handicapped Accessible and Fair Housing Jurisdiction and invites the submission of proposals from Minority and Women-owned firms.
L7257 Date of Publication: 04/18/2024
4455421
IN THE FOURTEENTH JUDICIAL CIRCUIT COURT
IN AND FOR JACKSON COUNTY, FLORIDA
STATE OF FLORIDA
DEPARTMENT OF TRANSPORTATION,
Petitioner,
v. Civil Action No: 2022-171-CA
Parcel No: 115
UNKNOWN HEIRS, BENEFICIARIES, DEVISESS, LEGATEES, SPOUSE AND CREDITORS OF MAMIE S. HARTSFIELD AND I. CICERO HARTSFIELD, TRUSTEES OF THE MAMIE S. HARTSFIELD LIVING TRUST U/A/D JUNE 12, 2002, MAMIE S. HARTSFIELD, DECEASED, RITCHIE H. BROWN, DECEASED, DAVID S. HARTSFIELD, DECEASED, MINERVA H. FIELDS, DECEASED, I. CICERO HARTSFIELD, DECEASED, ELEANOR HARTSFIELD, PENNY WHITE, VERONICA YOUNG, TIFFANY WASHINGTON, DAVID HARTSFIELD, II, KRISTIE HARTSFIELD, RECHA EVANS, CHARLES K. FIELDS, II, JOSEPH T. FIELDS, REBA HARTSFIELD, IDUS C. HARTSFIELD, II ASHLEY HARTSFIELD, REBA H. GIDDENS, RICHARD A. HARTSFIELD, II, MARY L. HARTSFIELD, PENNY H. BRYANT, and others,
Defendants.
____________________________________________/
NOTICE OF HEARING
YOU ARE HEREBY NOTIFIED that the undersigned has called the following up for hearing:
MATTER: Petitioner’s Motion to Approve, Confirm and Ratify
the Report of the Administrator Ad Litem
DATE: Friday, May 3, 2024
TIME: 11:00 a.m. Central Standard Time –
Fifteen (15) Minutes
JUDGE: Honorable Christopher N. Patterson
LOCATION: Via Zoom
Join Zoom Meeting
https://zoom.us/j/5750510920
Meeting ID: 575 051 0920
To appear by phone:
Dial any of the phone numbers below and enter the
Meeting ID number followed by #: 1-312-626-6799
Meeting ID: 575 051 0920#PLEASE GOVERN YOURSELF ACCORDINGLY
If you are a person with a disability who needs any accommodation in order to participate in this proceeding, you are entitled, at no cost to you, to the provision of certain assistance. Please contact the ADA Coordinator by mail at P. O. Box 1089, Panama City, FL 32402 or by phone at (850) 767-3550 at least seven (7) days before your scheduled court appearance, or immediately upon receiving this notification if the time before the scheduled appearance is less than seven (7) days. If you are hearing or voice impaired, please call 711 or email [email protected].
STATE OF FLORIDA
DEPARTMENT OF TRANSPORTATION
By: /s/ Erin Oliver
Erin Oliver
Florida Bar No: 0021177
Assistant General Counsel
Office of the General Counsel
Florida Department of Transportation – District 3
1074 Highway 90 East
Chipley, Florida 32428-2162
Telephone (850) 330-1293
Facsimile (850) 330-1758
[email protected]
[email protected]
[email protected]
CERTIFICATE OF SERVICE
I HEREBY CERTIFY that a true and correct copy of the foregoing Notice of Hearing on Petitioner’s Motion to Approve, Confirm and Ratify the Report of the Administrator Ad Litem has been filed with the Florida E-Portal and a copy of the same should be furnished to all counsel of record through that system. Additionally, the Notice of Hearing on Petitioner’s Motion to Approve, Confirm and Ratify the Report of the Administrator Ad Litem will be published in a local Jackson County newspaper for two (2) consecutive weeks.
This 3rd day of April 2024.
/s/ Erin Oliver
Erin Oliver
Assistant General Counsel
Florida Department of
TransportationL7226 Dates of Publication: 04/11/2024, 04/18/2024
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT, IN AND FOR JACKSON COUNTY, FLORIDA
PROBATE DIVISION
File No. 24-77-CP
IN RE: ESTATE OF
KATIE BARTLETT,
Deceased.
NOTICE TO CREDITORS
The administration of the Estate of Katie Bartlett, deceased, whose date of death was January 27, 2024, File Number 24-77-CP, is pending in the Circuit Court for Jackson County, Florida, Probate Division, the address of which is the Jackson County Clerk, 4445 Lafayette St., Marianna, FL 32446. The names and addresses of the Personal Representative and the Personal Representative’s attorney are set forth below.
All creditors of the decedent and other persons who have claims or demands against decedent’s Estate, including unmatured, contingent, or unliquidated claims and who may have been served a copy of this notice must file their claims with this Court WITHIN THE LATER OF THREE MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE OR THIRTY DAYS AFTER THE DATE OF SERVICE OF A COPY OF THIS NOTICE ON THEM.
All other creditors of the decedent and other persons who have claims or demands against the decedent’s Estate, including unmatured, contingent, or unliquidated claims must file their claims with this Court WITHIN THREE MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE.
ALL CLAIMS NOT SO FILED WILL BE FOREVER BARRED.
NOTWITHSTANDING THE TIME PERIODS SET FORTH ABOVE, ANY CLAIMS FILED TWO YEARS OR MORE AFTER THE DECEDENT’S DATE OF DEATH IS BARRED.
The date of the first publication of this notice is: April 11th, 2024.
STACIE HILL
Petitioner/executor 12810 Labelle Road
Beaumont, TX 77705
KRISTI MILLER NOVONGLOSKY
Florida Bar No. 0182044
Post Office Box 1129
Chipley, Florida 32428
Telephone: (850) 6387587
[email protected]
Attorney for Petitioner
L7227
Dates of Pubication: 04/11/2024, 04/18/2024
CONCURRENT NOTICE
NOTICE OF FINDING OF NO SIGNFICANT IMPACT AND
NOTICE OF INTENT TO REQUEST RELEASE OF FUNDS
April 18, 2024
Town of Malone
5182 9th Avenue
Malone, FL 32445
(850) 569-2308
These notices shall satisfy two separate but related procedural requirements for activities to be undertaken by the Town of Malone.
REQUEST FOR RELEASE OF FUNDS
On or about May 7, 2024, the Town of Malone will submit a request to the Florida Department of Commerce (FC) for the release of Community Development Block Grant funds under Title I of the Housing and Community Development (HCD) Act of 1974, as amended, to undertake a project to build a Critical Protection Facility for Town Public Works operations to replace the damaged, substandard pole barn structure currently being used. The building will withstand hurricane force winds and possess enough storage space to sufficiently house heavy equipment, tools, and other essential resources vital for emergency operations and response. The estimated total cost of the project is $1,700,000.00 with $1,700,000.00 in HUD funds; FC agreement #MT142.
FINDING OF NO SIGNIFICANT IMPACT
The Town of Malone has determined that the project will have no significant impact on the human environment. Therefore, an Environmental Impact Statement under the National Environmental Policy Act of 1969 (NEPA) is not required. Additional project information is contained in the Environmental Review Record (ERR) on file at Town of Malone Town Hall, 5182 9th Avenue, and may be examined or copied weekdays 9:00 A.M to 3:00 P.M.
PUBLIC COMMENTS
Any individual, group, or agency may submit written comments on the ERR to the Town of Malone. All comments must be received May 6, 2024. Comments will be considered prior to the Town of Malone requesting a release of funds. Comments should specify which notice they are addressing.
RELEASE OF FUNDS
The Town of Malone certifies to the Florida Department of Commerce and HUD that Linda Wilson in her capacity as Town Clerk consents to accept the jurisdiction of the Federal Courts if an action is brought to enforce responsibilities in relation to the environmental review process and that these responsibilities have been satisfied. The State’s approval of the certification satisfies its responsibilities under NEPA and related laws and authorities and allows the Town of Malone to use the CDBG funds.
OBJECTIONS TO RELEASE OF FUNDS
FC will accept objections to its release of funds and the Town of Malone certification for a period of fifteen days following the anticipated submission date or its actual receipt of the request (whichever is later) only if they are on one of the following bases: (a) the certification was not executed by the Certifying Officer of the Town of Malone; (b) the Town of Malone has omitted a step or failed to make a decision or finding required by HUD regulations at 24 CFR part 58; (c) the grant recipient has committed funds or incurred costs not authorized by 24 CFR Part 58 before approval of a release of funds by the State; or (d) another Federal agency acting pursuant to 40 CFR Part 1504 has submitted a written finding that the project is unsatisfactory from the standpoint of environmental quality. Objections must be prepared and submitted in accordance with the required procedures at 24 CFR Part 58, Sec. 58.76 and shall be addressed to the Florida Department of Commerce, CDBG Program, MSC-400, 107 East Madison Street, Tallahassee, FL 32399-6508. Potential objectors should contact the Town of Malone to verify the actual last day of the objection period.
Linda Wilson, Town Clerk
L7258 Date of Publication: 04/18/2024
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT, IN AND FOR JACKSON COUNTY, FLORIDA
PROBATE DIVISION
File No. 24-99-CP
IN RE: ESTATE OF
BOBBY BREEN HUGHES SR.,
Deceased.
NOTICE TO CREDITORS
The administration of the Estate of Bobby Breen Hughes, Sr., deceased, whose date of death was February 18, 2024, File Number 24-99-CP, is pending in the Circuit Court for Jackson County, Florida, Probate Division, the address of which is the Jackson County Clerk, 4445 Lafayette St., Marianna, FL 32446. The names and addresses of the Personal Representative and the Personal Representative’s attorney are set forth below.
All creditors of the decedent and other persons who have claims or demands against decedent’s Estate, including unmatured, contingent, or unliquidated claims and who may have been served a copy of this notice must file their claims with this Court WITHIN THE LATER OF THREE MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE OR THIRTY DAYS AFTER THE DATE OF SERVICE OF A COPY OF THIS NOTICE ON THEM.
All other creditors of the decedent and other persons who have claims or demands against the decedent’s Estate, including unmatured, contingent, or unliquidated claims must file their claims with this Court WITHIN THREE MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE.
ALL CLAIMS NOT SO FILED WILL BE FOREVER BARRED.
NOTWITHSTANDING THE TIME PERIODS SET FORTH ABOVE, ANY CLAIMS FILED TWO YEARS OR MORE AFTER THE DECEDENT’S DATE OF DEATH IS BARRED.
The date of the first publication of this notice is: April 11th, 2024.
BOBBY BREEN HUGHES, JR. Petitioner/executor
3240 Gatsby Lane
Montgomery, AL 36106
KRISTI MILLER NOVONGLOSKY
Florida Bar No. 0182044
Post Office Box 1129
Chipley, Florida 32428
Telephone: (850) 6387587
[email protected]
Attorney for Petitioner
L7230
Dates of Pubication: 04/11/2024, 04/18/2024
CITY OF COTTONDALE
Request for Submittals
Program Administration and/or Engineering Services
RFP/RFQ 2024-01
The City of Cottondale, Florida invites bids/proposals from qualified individuals or firms interested in providing grant administration services and/or engineering services related to the Florida Small Cities Community Development Block Grant (CDBG) in the Neighborhood Revitalization category. The City has been awarded CDBG Grant #23DB-N08 H2545 in the amount of $600,000.00 for the FFY 2021-22 funding cycle; therefore, procurement and contracting will follow CDBG regulations.
All responses will be ranked on an individual and equal basis.
Ranking criteria and requirements may be requested in person by contacting Sherri McBride, City Clerk, at 2659 Front Street, Cottondale, FL 32431 or by telephone at (850) 352-4361 or via email [email protected].
Responses will be due by Wednesday, May 8, 2024 at
12 PM Noon. Submit to the City of Cottondale, ATTN: Sherri McBride, PO Box 398; 2659 Front Street, Cottondale, FL 32431.
EQUAL OPPORTUNITY EMPLOYER
HANDICAP ACCESSIBLE/FAIR HOUSING JURISDICTION
L7256
Date of Publication: 04/18/2024
NOTICE OF PUBLIC HEARING
OF INTENT TO ADOPT A RESOLUTION
TO ABANDON A PORTION OF ALLEY LOCATED BETWEEN LOTS 3 AND 4, BLOCK 26 WITHIN THE INCORPORATED LIMITS OF THE TOWN OF GRAND RIDGE, FLORIDA
NOTICE IS HEREBY GIVEN that the Town Council in and for the Town of Grand Ridge, Florida, will consider the adoption of a resolution to abandon/close a platted alley, located within the incorporated Limits of the Town of Grand Ridge, Florida, and more particularly described as:
That certain platted alley between lots 3 and 4, Block 26 in the Town of Grand Ridge, Florida according to the plat thereof on file in the Office of the Clerk of Circuit Court of Jackson County, Florida.
Any person wishing to be heard on this issue should be present at the following meeting:
The passage of the proposed Resolution to abandon/close that portion of the public alley located between Lots 3 and 4, Block 26 in the Town of Grand Ridge, Florida will be considered at the regular meeting of the Town Council of the Town of Grand Ridge, Florida, at 6:00 P.M., C.S.T., on Thursday, May 2, 2024, at the Grand Ridge Multi-Purpose Building located at 6910 Hall Street, Grand Ridge, Florida 32442.
A copy of the proposed Resolution can be inspected by the public at the Office of the Town Clerk during regular working hours.
If you are a person with a disability who needs any accommodation in order to participate in the meeting, you are entitled, at no cost to you, to the provision of certain assistance. Please contact the Town Clerk, Amanda Applewhite, at Town Hall by calling 850-592-4621 at least three (3) days prior to the meeting.
L7255
Date of Publication: 04/18/2024
4455421
IN THE FOURTEENTH JUDICIAL CIRCUIT COURT
IN AND FOR JACKSON COUNTY, FLORIDA
STATE OF FLORIDA
DEPARTMENT OF TRANSPORTATION,
Petitioner,
v. Civil Action No: 2022-166-CA
Parcel No: 114
UNKNOWN HEIRS OF DIANA H. SPENCER,
DECEASED, and others,
Defendants.
____________________________________________/
NOTICE OF HEARING
YOU ARE HEREBY NOTIFIED that the undersigned has called the following up for hearing:
MATTER: Petitioner’s Motion to Approve, Confirm and Ratify
the Report of the Administrator Ad Litem
DATE: Friday, May 3, 2024
TIME: 11:00 a.m. Central Standard Time –
Fifteen (15) Minutes
JUDGE: Honorable Christopher N. Patterson
LOCATION: Via Zoom
Join Zoom Meeting
https://zoom.us/j/5750510920
Meeting ID: 575 051 0920
To appear by phone:
Dial any of the phone numbers below and enter the
Meeting ID number followed by #: 1-312-626-6799
Meeting ID: 575 051 0920#PLEASE GOVERN YOURSELF ACCORDINGLY.
If you are a person with a disability who needs any accommodation in order to participate in this proceeding, you are entitled, at no cost to you, to the provision of certain assistance. Please contact the ADA Coordinator by mail at P. O. Box 1089, Panama City, FL 32402 or by phone at (850) 767-3550 at least seven (7) days before your scheduled court appearance, or immediately upon receiving this notification if the time before the scheduled appearance is less than seven (7) days. If you are hearing or voice impaired, please call 711 or email [email protected].
STATE OF FLORIDA
DEPARTMENT OF TRANSPORTATION
By: /s/ Erin Oliver
Erin Oliver
Florida Bar No: 0021177
Assistant General Counsel
Office of the General Counsel
Florida Department of Transportation – District 3
1074 Highway 90 East
Chipley, Florida 32428-2162
Telephone (850) 330-1293
Facsimile (850) 330-1758
[email protected]
[email protected]
[email protected]
CERTIFICATE OF SERVICE
I HEREBY CERTIFY that a true and correct copy of the foregoing Notice of Hearing on Petitioner’s Motion to Approve, Confirm and Ratify the Report of the Administrator Ad Litem has been filed with the Florida E-Portal and a copy of the same should be furnished to all counsel of record through that system. Additionally, the Notice of Hearing on Petitioner’s Motion to Approve, Confirm and Ratify the Report of the Administrator Ad Litem will be published in a local Jackson County newspaper for two (2) consecutive weeks.
This 3rd day of April 2024.
/s/ Erin Oliver
Erin Oliver
Assistant General Counsel
Florida Department of
TransportationL7225 Dates of Publication: 04/11/2024, 04/18/2024
NOTICE OF PUBLIC SALE:
H & H ENTERPRISES gives notice that on 05/16/2024 at 10:00 AM the following vehicles(s) may be sold by public sale at 4421 JACKSON ST MARIANNA, FL 32448 to satisfy the lien for the amount owed on each vehicle for any recovery, towing, or storage services charges and administrative fees allowed pursuant to Florida statute 713.78.
1FMCU0C75CKC43625
2012 FORD
L7238
Date of Publication: 04/18/2024
NOTICE OF PUBLIC SALE:
H & H ENTERPRISES gives notice that on 05/13/2024 at 10:00 AM the following vehicles(s) may be sold by public sale at 4421 JACKSON ST MARIANNA, FL 32448 to satisfy the lien for the amount owed on each vehicle for any recovery, towing, or storage services charges and administrative fees allowed pursuant to Florida statute 713.78.
5N1AR2MN1EC662926
2014 NISS
L7232
Date of Publication: 04/18/2024
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT IN AND FOR JACKSON COUNTY, FLORIDA
PROBATE DIVISION
FILE NO.:24000035CPAXMX
IN RE: THE ESTATE OF
MARY ELLA WARD
Deceased
______________/
NOTICE TO CREDITORS
The administration of the estate of MARY ELLA WARD, deceased, File Number 2024 CP 0035 is pending in the Circuit Court for Jackson County, Florida, Probate Division, the address of which is 4445 Lafayette Street, Marianna, FL 32446. The name and address of the personal representative and the personal representative’s attorney are set forth below.
ALL INTERESTED PERSONS ARE NOTIFIED THAT:
All persons upon whom this notice is served who have objections that challenge the qualifications of the personal representative, venue, or jurisdiction of this Court are required to file their objections with this Court WITHIN THE LATER OF THREE MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE OR THIRTY DAYS AFTER THE DATE OF SERVICE OF A COPY OF THIS NOTICE ON THEM.
All creditors of the decedent and other persons having claims or demands against decedent’s estate on whom a copy of this notice is served within three months after the date of the first publication of this notice must file their claims with this Court WITHIN THE LATER OF THREE MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE OR THIRTY DAYS AFTER THE DATE OF SERVICE OF A COPY OF THIS NOTICE ON THEM.
All other creditors of the decedent and persons having claims or demands against the decedent’s estate must file their claims with this Court WITHIN THREE MONTHS AFTER THE DATE OF THE FIRST PUBLICATION OF THIS NOTICE.
ALL CLAIMS, DEMANDS AND OBJECTIONS NOT SO FILED WILL BE FOREVER BARRED.
The dates of publication of this Notice are April 18th and April 25th, 2024.
Personal Representative:
Shilee Nichole Wells 7 Kelley Way Valparaiso, Florida 32580
Attorney for Personal Representative
Richard S. Johnson, P.A.
107 N. Partin Drive
Niceville, Florida 32578
Telephone: (850) 279-6868
Fax: (850) 678-8336
L7231
Dates of Publication: 04/18/2024, 04/25/2024
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT IN AND FOR JACKSON COUNTY, FLORIDA
CASE NO. 32-2023-CA-000019-CAAM
CHIPOLA AREA HABITAT FOR HUMANITY, INC. (formerly Jackson County Habitat for Humanity, Inc.) A Florida Not For Profit Corporation
Plaintiffs,
vs
ROBERT PIERSON, deceased August 2019 and any unknown parties claiming as heirs, devisees, grantees, assigns, lienors, creditors, trustees or other claimants of the said ROBERT PIERSON, JOHNATHAN ROBERT PIERSON, deceased February 2022, And unknown heirs, or other claimants of the said JOHNATHAN ROBERT PIERSON, and CRYSTLE NICOLE CLARK,
Defendants
____________________________________________/
NOTICE OF SALE
NOTICE IS HEREBY GIVEN pursuant to a Final Judgment of Foreclosure dated the 21st day of March, 2024 entered in Civil Case No. 32-2023-CA-000019-CAAM of the Circuit Court of the Fourteenth Judicial Circuit in and for Jackson County, Florida, wherein CHIPOLA AREA HABITAT FOR HUMANITY, INC., is Plaintiff, and ROBERT PIERSON, deceased, JOHNATHAN ROBERT PIERSON, deceased, and CRYSTLE NICOLE CLARK are Defendants;
I will sell to the highest bidder for cash online at www.jackson.realforeclose.com, the Clerk’s website for on-line auctions, on May 9, 2024 beginning at 11:00 a.m. (CST) the following described property as set forth in said Order or Final Judgment, to wit:
Property Address: 2958 Hillcrest Drive, Marianna, FL 32448.
Legal Description:
LOT 17, OF BLOCK C, SUNSET HEIGHTS, A SUBDIVISION OF PARTS OF THE NW 1/4 OF THE NW 1/4 AND THE SW 1/4 OF THE NW 1/4 OF SECTION 5, TOWNSHIP 4 NORTH, RANGE 10 WEST, AND A PART OF THE NE 1/4 OF THE NW 1/4 OF SAID SECTION 5, PUBLIC RECORDS OF JACKSON COUNTY, FLORIDA. PIN 05-4N-10-0403-00C0-0170
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the lis pendens, must file a claim withing 60 days after the sale.
NOTICE OF SALE DATED: this 9th day of May, 2024.
CLERK OF THE COURT
Honorable CLAYTON O. ROOKS, III
4445 Lafayette St
Marianna, FL 32448
By: __________
Deputy Clerk
If you are a person with a disability who needs any accommodation in order to participate in this proceeding, you are entitled, at no cost to you, to the provision of certain assistance. Please contact the ADA Coordinator by mail at Post Office Box 1089, Panama City, FL 32402 or by phone at (850) 767-3550 at least seven (7) days before your scheduled court appearance, or immediately upon receiving this notification if the time before the scheduled appearance is less than seven (7) days. If you are hearing or voice impaired, please call 711 or email [email protected].
L7215 Dates of Publication: 04/18/2024, 04/25/2024
IN THE CIRCUIT COURT OF THE 14TH JUDICIAL CIRCUIT, IN AND FOR JACKSON COUNTY, FLORIDA
CIVIL DIVISION
CASE NO. 22000005CAAXMX
FEDERAL HOME LOAN MORTGAGE CORPORATION, AS TRUSTEE FOR THE BENEFIT OF THE SEASONED LOANS STRUCTURED TRANSACTION TRUST, SERIES 2018-1,
Plaintiff,
vs.
CINDY STEVENS; UNKNOWN SPOUSE OF CINDY STEVENS; UNKNOWN PERSON(S) IN POSSESSION OF THE SUBJECT PROPERTY,
Defendant(s)
______________/
AMENDED RE-NOTICE OF FORECLOSURE SALE
(Please publish in JACKSON COUNTY TIMES)
NOTICE IS HEREBY GIVEN pursuant to an Order Rescheduling Foreclosure Sale filed March 19, 2024 and entered in Case No. 22000005CAAXMX, of the Circuit Court of the 14th Judicial Circuit in and for JACKSON County, Florida, wherein FEDERAL HOME LOAN MORTGAGE CORPORATION, AS TRUSTEE FOR THE BENEFIT OF THE SEASONED LOANS STRUCTURED TRANSACTION TRUST, SERIES 2018-1 is Plaintiff and CINDY STEVENS; UNKNOWN SPOUSE OF CINDY STEVENS; UNKNOWN PERSON(S) IN POSSESSION OF THE SUBJECT PROPERTY; are defendants. CLAYTON O. ROOKS, III, the Clerk of the Circuit Court, will sell to the highest and best bidder for cash www.jackson.realforeclose.com, at 4445 LAFAYETTE STREET, MARIANNA in JACKSON County, FLORIDA 32446, at 11:00 A.M., on May 9, 2024, the following described property as set forth in said Final Judgment, to wit:
LOTS 9, 11, AND 13 IN BLOCK (31) KING ADDITION TO THE CITY OF GRACEVILLE, JACKSON COUNTY, FLORIDA.
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the lis pendens must file a claim before the Clerk reports the surplus as unclaimed.
Dated this 3rd day of April, 2024.
CLAYTON O. ROOKS, III
As Clerk of said Court
By /s/ Marissa Driggers
As Deputy Clerk
This Notice is provided pursuant to Administrative Order No. 2.065. In accordance with the Americans with the Disabilities Act, If you are a person with a disability who needs any accommodation in order to participate in this proceeding, you are entitled, at no cost to you, to the provision of certain assistance. Please contact the ADA Coordinator by mail at P.O. Box 1089, Panama City, Florida 32402 or by phone at (850) 747-5338 at least seven (7) days before your scheduled court appearance, or immediately upon receiving this notification if the time before the scheduled appearance is less than seven (7) days. If you are hearing impaired, please call 711.
Submitted by:
Kahane & Associates, P.A.
1619 NW 136th Avenue,
Suite D-220
Sunrise, Florida 33323
Telephone: (954) 382-3486
Telefacsimile: (954) 382-5380
Designated service email: [email protected]
L7233 Dates of Publication: 04/18/2024, 04/25/2024
ADVERTISEMENT FOR BIDS
CITY OF MARIANNA, FLORIDA
CITYWIDE WASTEWATER & WATER RESTORATION PROJECT
City of Marianna (Owner) is requesting Bids for the construction of the
following Project:
Citywide Wastewater & Water Restoration Project
FloridaCommerce
CDBG-DR M0011 & M0101
DHM MAR22WW & MAR22WM
Bids for the construction of the Project will be received at the City of Marianna Clerk’s Office located at 2895 Jefferson Street, Marianna, FL 32446, until Thursday, June 13, 2024, at 2:00 PM local time. At that time, or shortly thereafter, the Bids received will be publicly opened and read at the Marianna City Hall Commission Chambers located at 2897 Jefferson Street, Marianna, FL 32446.
The Project includes the following Work:
Project consists of: (1) Sewer collection system rehabilitation to reduce I&I, including CCTV inspection of 75,925 LF of sewer lines (6” – 16” diameter), CIPP lining of 3,000 LF of gravity sewer, lining 32 brick manholes, replace 20 sewer laterals; final scope of repairs will be based on results of inspection report, (2) Rehabilitation of Davis Field Sewer Lift Station, (3) Construction of gravity sewer improvements including approximately 30 LF of 6”, 2,358 LF of 8”, 3,248 LF of 12”, and 15,767 LF of 24” PVC sewer pipe, 74 manholes, 3 jack & bores (16”, 24” and 36” casings), and (4) Construction of water system improvements including 40 LF of 4” PVC WM, 410 LF of 6” WM, 365 LF of 8” WM, 1,196 LF of 10” WM and 3,592 LF of 12” WM, associated valves and fittings, 11 fire hydrants, water services and fire protection lines and other appurtenances and improvements described in the construction Drawings.
Plans, specifications, and contract documents will be made available and open to public inspection at the office listed above or may be obtained from:
DHM Melvin Engineering
4428 Lafayette Street
Marianna, Florida 32446
(850) 482-3045
[email protected]
upon payment of $125.00 per set which amount constitutes the cost of reproduction and handling. This payment will not be refunded. Electronic copies will be provided at no cost.
A non-mandatory pre-bid conference shall be held at the office of DHM Melvin Engineering, 4428 Lafayette Street, Marianna FL 32446, at 10:00 AM CT, Thursday, May 2, 2024.
For all further requirements regarding bid submittal, qualifications, procedures, and contract award, refer to the Instructions to Bidders that are included in the Bidding Documents.
Small business and minority businesses, women’s business enterprises, and labor surplus area firms are encouraged to submit proposals, and firms using such subcontractors are strongly encouraged to solicit such firms in the subcontracting process. Any Contracts/subcontracts issued under this procurement must comply with the necessary affirmative steps to assure that minority businesses, women’s business enterprises, and labor surplus area firms are used when possible, in accordance with 2 CFR § 200.321.
EQUAL OPPORTUNITY EMPLOYER HANDICAP
ACCESSIBLE/FAIR HOUSING JURISDICTION
L7237 Dates of Publication: 04/18/2024, 04/25/2024
INVITATION TO BID
In accordance with the Live Local Act (SB 102), the Jackson County Board of County Commissioners is requesting bids from individuals, firms, and non-profit organizations to purchase and develop attainable housing on one or more of the fifteen (15) surplus land plots within Jackson County.
Sealed bids will be accepted by the Jackson County Board of County Commissioners at the Purchasing Office located at the Jackson County Administration building, 2864 Madison Street, Marianna, FL 32448 until 2:00 pm CST on Thursday, May 9, 2024, for the following project:
BID NUMBER: 2324-01
BID NAME: SURPLUS LAND FOR ATTAINABLE HOUSING
SUBMISSION DEADLINE: May 9, 2024 by 2:00 pm CST
BID OPENING: Bids will be opened and recorded by the Purchasing Office of the Jackson County Board of County Commissioners located at 2864 MADISON STREET, Marianna, Florida 32448 on Thursday, May 9, 2024, at 2:00pm, or shortly thereafter.
Specifications and official ITB Documents can be accessed online at Central Bidding (www.centralbidding.com). For questions related to the electronic bidding process, please call Central Bidding at 225-810-4814. Electronic Bids may be submitted at Central Bidding (www.centralbidding.com). Questions regarding the specifications or ITB should be directed to Lynsey Darragh, Procurement Officer by email at [email protected]
List of bidders and awards (if any) shall be announced at a meeting of the Jackson County Board of County Commissioners. Bid award(s) will be made to the best bidder(s), but the right is reserved to reject any or all bids.
Board of County Commissioners
By: Paul Donofro, Jr.
BOARD CHAIRMAN Clayton. O. Rooks
CLERK OF CIRCUIT COURT
L7234
Dates of Publication: 04/18/2024, 04/25/2024
City of Marianna, FL
Invitation to Bid
Recreational Lighting
Upgrade Project
The City of Marianna is seeking sealed bids from professional sports lighting firms to complete a Recreational Lighting Upgrade Project to provide adequate sports lighting for Baseball Field’s #3 and #4 at the Marianna Educational Recreational Expo (MERE) in Marianna, FL. This “turnkey” Project includes the replacement of outdated light fixtures along 12 existing light poles including associated light bulbs, electrical wiring, switches, and other required electrical/lighting components.
Bids for these services will be received until 2:00 PM CST, Thursday, May 2, 2024, at the City of Marianna Clerk’s Office located at 2895 Jefferson Street, Marianna, FL 32446. At that time, or shortly thereafter, the Bids received will be publicly opened and read at the Marianna City Hall Commission Chambers located at 2897 Jefferson Street, Marianna, FL 32446.
For additional information and to obtain the project BID documents contact Nikki Mayberry, City of Marianna, Grants Coordinator by phone at (850) 482-4353 or Email [email protected]. Specific questions related to the project or to schedule a site visit contact Jeff Faircloth by phone at (850) 693-5188 or Email [email protected].
To be considered, the bidder must submit one (1) manually signed original of the SUBMITTAL in a sealed envelope or package, clearly marked with the respondent’s name and address, and the words:
“Recreational Lighting Upgrade Project” addressed to:
City of Marianna
City Clerk’s Office
2895 Jefferson Street
Marianna, FL 32446
Small business and minority businesses, women’s business enterprises, and labor surplus area firms are encouraged to submit proposals, and firms using such subcontractors are strongly encouraged to solicit such firms in the subcontracting process. Any Contracts/subcontracts issued under this procurement must comply with the necessary affirmative steps to assure that minority businesses, women’s business enterprises, and labor surplus area firms are used when possible, in accordance with 2 CFR § 200.321.
EQUAL OPPORTUNITY EMPLOYER HANDICAP ACCESSIBLE/FAIR HOUSING JURISDICTION
L7236
Dates of Publication: 04/18/2024, 04/25/2024
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT
IN AND FOR JACKSON COUNTY, FLORIDA
CASE NUMBER: 23-268 CA
CITY OF MARIANNA, a Florida
Municipal corporation,
Plaintiff,
vs.
AUSTIN T. MERRITT, JOY FEARS
a/k/a JOY FAYE FEARS, SAVANNAH
MEOLA and KRISTI MERRITT,
Defendants.
____________________________________________/
NOTICE OF SALE
NOTICE is hereby given that pursuant to the Summary Final Judgment of Foreclosure dated the 10th day of April, 2024, in Case Number 2023-268-CA, of the Circuit Court of the Fourteenth Judicial Circuit, in and for Jackson County, Florida, wherein CITY OF MARIANNA, a Florida municipal corporation, is Plaintiff and AUSTIN T. MERRITT, JOY FEARS a/k/a JOY FAYE FEARS, SAVANNAH MEOLA AND KRISTI MERRITT are the Defendants, I will sell to the highest and best bidder by public electronic sale at https://jackson.realforeclose.com, at 11:00 A.M., CT, on the 16th day of MAY, 2024, the following described real property, as set forth in the Summary Final Judgment of Foreclosure, to-wit:
North ½ of lot of land containing one acre deeded to Laura Holder by Mrs. G. C. Erwin (Book MM, Page 198), in the SE ¼ of SE ¼ of Section 31, Township 6 North, Range 9 West, being 105 feet North and South by 210 feet East and West and situated on East side of Greenwood and Gordon Road (Highway No. 71) bounded on the North by W.B. Dickson, Jr. property and on the South by Henry T. Hey property, Greenwood, Jackson County, Florida, LESS existing road rights-of-way.
The North 12 feet of the following: S ½ of lot on East side of Gordon Road, North of Methodist Church lot, known as Laura Holder lot, described as follows: Beginning at the SE corner of the N. L. Pender lot, thence run West 70 yards to Greenwood and Gordon Road, thence South along said road 35 yards to the NW corner of Methodist Parsonage lot, thence East along the northern boundary of said Methodist Parsonage lot 75 yards, thence North 35 yards to the Point of Beginning, being a part of Section 31, Township 6 North, Range 9 West, in the Town of Greenwood, Florida.
Together with a 1982 Double-Wide mobile home (52 foot), VIN# 3320132467A and 3320132467B, which is attached to said real property.
AT THE TIME OF THE SALE, THE SUCCESSFUL HIGH BIDDER OR BIDDERS, AS THE CASE MAY BE, SHALL POST WITH THE CLERK A DEPOSIT EQUAL TO 5 PERCENT OF THE FINAL BID. THE DEPOSIT SHALL BE APPLIED TO THE SALE PRICE AT THE TIME OF PAYMENT. THE SUM REMAINING DUE AND OWING AFTER APPLICATION OF THE DEPOSIT SHALL BE PAID TO THE CLERK IN CERTIFIED FUNDS IN ACCORDANCE WITH THE POLICY OF THE CLERK OF COURT.
THE SUCCESSFUL BIDDER, OR BIDDERS, AT THE SALE WILL BE REQUIRED TO PLACE THE REQUISITE STATE DOCUMENTARY STAMPS ON THE CERTIFICATE OF TITLE.
If you are a person claiming a right to funds remaining after the sale, you must file a claim with the Clerk no later than 60 days after the sale. If you fail to file a claim, you will not be entitled to any remaining funds. After 60 days, only the owner of record, as of the date of the Lis Pendens, may claim the surplus.
DATED this 11th day of April, 2024.
CLAYTON O. ROOKS, III, CLERK
Jackson County, Florida
By: /s/ Abigail Perkins As Deputy Clerk
L7235 Dates of Publication: 04/18/2024, 04/25/2024
IN THE CIRCUIT COURT OF THE FOURTEENTH JUDICIAL CIRCUIT
IN AND FOR JACKSON COUNTY, FLORIDA
CIVIL DIVISION
CASE NO. 22000219CAAXMX
Division No.
MORGAN STANLEY RESIDENTIAL MORTGAGE
LOAN TRUST 2020-RPL1
Plaintiff,
vs.
SUSAN J FAIRCLOTH, et al,
Defendants
____________________________________________/
NOTICE OF SALE
PURSUANT TO CHAPTER 45
NOTICE IS HEREBY GIVEN pursuant to an Order dated April 5, 2024, and entered in Case No. 22000219CAAXMX of the Circuit Court of the FOURTEENTH Judicial Circuit in and for Jackson County, Florida, wherein Morgan Stanley Residential Mortgage Loan Trust 2020-RPL1 is the Plaintiff and SPRINGCASTLE CREDIT FUNDING TRUST, THROUGH ITS TRUSTEE WILMINGTON TRUST, NATIONAL ASSOCIATION, PORTFOLIO RECOVERY ASSOCIATES, LLC ASSIGNEE FOR CITIBANK, N.A., SUSAN J FAIRCLOTH, and UNKNOWN TENANT # 1 the Defendants. Clayton O. Rooks, III, Clerk of the Circuit Court in and for Jackson County, Florida will sell to the highest and best bidder for cash at https://jackson.realforeclose.com at 11:00 AM on May 23, 2024, the following described property as set forth in said Order of Final Judgment, to wit:
COMMENCING AT THE SW CORNER OF THE N 1/2 OF THE NE 1/4 OF THE SECTION 80, TOWNSHIP 5 NORTH, RANGE WEST, JACKSON COUNTY, FLORIDA; THENCE S89°46’50”E, ALONG THE SOUTH LINE OF THE N1/2 OF THE NE1/4, 1269.26 FEET TO THE POINT OF BEGINNING: THENCE CONTINUE S89°46’50”E, 210.0 FEET; THENCE N00°13’10”E, 210.0 FEET TO THE SOUTH SIDE OF A GRADED ROAD; THENCE N89°46’50”W, ALONG SAID GRADED ROAD, 210.0 FEET; THENCE S00°13’10”W, 210. FEET TO THE POINT OF BEGINNING. SAID PARCEL CONTAINS 1.01 ACRES, MORE OR LESS. TOGETHER WITH THAT CERTAIN 1986 FLEETWOOD GAFLSH2 (A&B) 12346127 DOUBLEWIDE MOBILE HOME.
IF YOU ARE A PERSON CLAIMING AN INTEREST IN THE SURPLUS FROM THE SALE, IF ANY, OTHER THAN THE PROPERTY OWNER AS OF THE DATE OF THE LIS PENDENS, YOU MUST FILE A CLAIM WITH THE CLERK OF COURT BEFORE OR NO LATER THAN THE DATE THAT THE CLERK REPORTS THE SURPLUS AS UNCLAIMED. IF YOU FAIL TO FILE A TIMELY CLAIM, YOU WILL NOT BE ENTITLED TO ANY REMAINING FUNDS. .AFTER THE FUNDS ARE REPORTED AS UNCLAIMED, ONLY THE OWNER OF THE RECORD AS OF THE DATE OF THE LIS PENDENS MAY CLAIM THE SURPLUS.
If the sale is set aside, the Purchaser may be entitled to only a return of the sale deposit less any applicable fees and costs and shall have no further recourse against the Mortgagor, Mortgagee or the Mortgagee’s Attorney.
DATED at Jackson County, Florida, this 11th day of April, 2024.
GILBERT GARCIA GROUP, P.A.
Attorney for Plaintiff
2313 W. Violet St.
Tampa, Florida 33603
Telephone: (813) 443-5087
Fax: (813) 443-5089
[email protected]
By: /s/ Amy M. Kiser
Amy M. Kiser, Esq.
Florida Bar No. 46196
832775.102200/tll
Published in: Jackson County Times
“In accordance with the Americans With Disabilities Act, persons in need of a special accommodation to participate in this proceeding shall, within seven (7) days prior to any proceeding, contact the Administrative Office of the Court, Jackson County, 4445 Lafayette Street, Marianna, FL 32446, Telephone (850) 482-9552, via Florida Relay Service”.
Apre ako ki fet avek Americans With Disabilites Act, tout moun kin ginyin yun bézwen spésiyal pou akomodasiyon pou yo patisipé nan pwogram sa-a dwé, nan yun tan rézonab an ninpot aranjman kapab fet, yo dwé kontakté Administrative Office Of The Court i nan niméro, Jackson County, 4445 Lafayette Street, Marianna, FL 32446, Telephone (850) 482-9552 i pasan pa Florida Relay Service.
En accordance avec la Loi des “Americans With Disabilities”. Les personnes en besoin d’une accomodation speciale pour participer a ces procedures doivent, dans un temps raisonable, avante d’entreprendre aucune autre démarche, contacter l’office administrative de la Court situé au, Jackson County, 4445 Lafayette Street, Marianna, FL 32446, Telephone (850) 482-9552 Via Florida Relay Service.
De acuerdo con el Acto ó Decreto de los Americanos con Impedimentos, Inhabilitados, personas en necesidad del servicio especial para participar en este procedimiento debrán, dentro de un tiempo razonable, antes de cualquier procedimiento, ponerse en contacto con la oficina Administrativa de la Corte , Jackson County, 4445 Lafayette Street, Marianna, FL 32446, Telephone (850) 482-9552 Via Florida Relay Service.
L7254 Dates of Publication: 04/18/2024, 04/25/2024
IN THE COUNTY COURT OF THE 14TH JUDICIAL CIRCUIT, IN AND FOR JACKSON COUNTY, FLORIDA.
CASE NO.: 2023-CC- 000333
JUDGE: DOUGLAS WADE MERCER
BE A MAN BUY LAND, LLC, a Florida limited liability company
Plaintiff,
v.
CHARLOTTE GREEN RAMOS, UNKNOWN SPOUSE OF CHARLOTTE GREEN RAMOS, RHONALD GLADE, UNKNOWN SPOUSE OF RHONALD GLADE AND UNKNOWN TENANT(S) IN POSSESSION, IF ANY,
Defendants.
____________________________________________/
Notice of Foreclosure Sale
(Please publish in Jackson County Times)
NOTICE IS HEREBY GIVEN pursuant to a Final Judgment of Foreclosure dated April 9, 2024 and entered in 322023CC000333CCAXMX of the Circuit Court of the Fourteenth Judicial Circuit in and for Jackson County, Florida, wherein BE A MAN BUY LAND, LLC, a Florida limited liability company, is the Plaintiff and CHARLOTTE GREEN RAMOS, UNKNOWN SPOUSE OF CHARLOTTE GREEN RAMOS, RHONALD GLADE, UNKNOWN SPOUSE OF RHONALD GLADE AND UNKNOWN TENANT(S) IN POSSESSION are the Defendants. Clayton O. Rooks, III as the Clerk of the Circuit Court will sell to the highest and best bidder for cash by electronic sale at Jackson County Clerk of Court online sales http://jackson.realforeclose.com/ at 11:00 a.m CST on June 6, 2024, the following described property as set forth in the Final Judgment of Foreclosure, to wit:
Parcel ID: 02-2N-11-0095-2200-0020
LOT 2, BLOCK 220, COMPASS LAKE HILLS, UNIT SIX, ACCORDING TO THE PLAT THEREOF AS RECORDED IN PLAT BOOK A-4 AT PAGES 141 THROUGH 150, INCLUSIVE, OF THE PUBLIC RECORDS OF JACKSON COUNTY, FLORIDA.
TOGETHER WITH all the improvements now or hereafter erected on the property, and all easements, appurtenances, and fixtures now or hereafter a part of the property.
Any person claiming an interest in the surplus from the sale, if any, other than the property owner as of the date of the lis pendens must file a claim before the clerk reports the surplus as unclaimed in accordance with Section 45.031, Florida Statutes.
Dated on April 9, 2024
Clerk of Court
Clayton O. Rooks, III
By: /s/ Abigail Perkins
As Deputy Clerk
AMERICAN WITH DISABILITIES NOTICE
If you are a person with a disability who needs any accommodation in order to participate in this proceeding, you are entitled, at no cost to you, to the provision of certain assistance. Please contact the ADA Coordinator by mail at P. O. Box 1089, Panama City, FL 32402 or by phone at (850) 767-3550 at least seven (7) days before your scheduled court appearance, or immediately upon receiving this notification if the time before the scheduled appearance is less than seven (7) days. If you are hearing or voice impaired, please call 711 or email [email protected].
Submitted By:
Rene S. Griffith
Attorney for Plaintiff
4260 SE Federal Highway
Stuart, Florida 34997
(772) 546-4101
[email protected]
L7259 Dates of Publication: 04/18/2024, 04/25/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
429 OF 2021
NOTICE IS HEREBY GIVEN THAT: SAMMIE D SIMMONS or DONNA G SIMMONS the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
429 OF 2021
Parcel ID:
29-6N-08-0000-0060-0030
Name in which Assessed
HARMON LEROY PERKINS
Description of Property:
A FIFTEEN (15) ACRE PARCEL LYING IN THE NORTHWEST QUARTER OF SECTION 29, TOWNSHIP 6 NORTH, RANGE 8 WEST. BEING BETTER DESCRIBED AS FOLLOWS: THE WEST HALF OF NORTHEAST QUARTER OF NORTHWEST QUARTER OF SECTION 29, TOWNSHIP 6 NORTH, RANGE 8 WEST, JACKSON COUNTY, FLORIDA LESS AND EXCEPT THE SOUTH 330 FEET OF SAID HALF.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7239
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO. 635 OF 2021
NOTICE IS HEREBY GIVEN THAT: SAMMIE D SIMMONS or DONNA G SIMMONS the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
635 OF 2021
Parcel ID:
23-5N-09-0000-0130-0030
Name in which Assessed
ROBERT NICHOLAS MATTHEWS
Description of Property:
BEGIN AT SOUTHEAST CORNER OF THE NORTH HALF OF SOUTHEAST QUARTER, SECTION 23, TOWNSHIP 5 NORTH, RANGE 9 WEST, THENCE WEST 1,767 FEET TO THE SOUTHEAST CORNER OF THE LAND DEEDED TO GUY LEE BRYANT BY DEED RECORDED IN OR BOOK 65, PAGE 137, THENCE NORTH 467 FEET, THENCE WEST 123 FEET TO POINT OF BEGINNING, THENCE WEST 811 FEET TO THE WEST LINE OF SAID NORTH ONE HALF OF SOUTHEAST ONE QUARTER, THENCE NORTH 853 FEET, THENCE EAST 811 FEET, THENCE SOUTH 853 FEET TO POINT OF BEGINNING.
ALSO: BEGINNING AT THE SOUTHWEST CORNER OF THE NORTHWEST ONE QUARTER OF THE SOUTHEAST ONE QUARTER OF SECTION 23, TOWNSHIP 5 NORTH, RANGE 9 WEST AND RUN THENCE EAST 467 FEET TO THE POINT OF BEGINNING; THENCE RUN NORTH 467 FEET; THENCE EAST 467 FEET; THENCE SOUTH 467 FEET; THENCE WEST 467 FEET.
ALSO: BEGINNING AT THE SOUTHWEST CORNER OF THE NORTHWEST ONE QUARTER OF THE SOUTHEAST ONE QUARTER OF SECTION 23, TOWNSHIP 5 NORTH, RANGE 9 WEST, AND RUN THENCE NORTH 467 FEET; THENCE EAST 467 FEET; THENCE SOUTH 467 FEET; THENCE WEST 467 FEET TO THE POINT OF BEGINNING ALL BEING IN JACKSON COUNTY, FLORIDA.
LESS AND EXCEPT THE FOLLOWING DESCRIBED PROPERTY: COMMENCE AT THE SOUTHEAST CORNER OF NORTH ONE HALF OF THE SOUTHEAST ONE QUARTER OF SECTION 23, TOWNSHIP 5 NORTH, RANGE 9 WEST, AND RUN WEST 1890.0 FEET, THENCE RUN NORTH 467.0 FEET TO AN IRON PIPE, THE POINT OF BEGINNING. THENCE RUN NORTH 853.0 FEET TO A CONCRETE MONUMENT, THENCE RUN WEST 324.0 FEET TO A CONCRETE MONUMENT, THENCE RUN SOUTH 853.0 FEET TO AN IRON PIPE, THENCE RUN EAST 324.0 FEET TO THE P.O.B. LYING AND BEING IN THE NORTH ONE HALF OF THE SOUTHEAST ONE QUARTER OF SAID SECTION, JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7240
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
2269 OF 2020
NOTICE IS HEREBY GIVEN THAT: CLAUDIUS KESSLER the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
2269 OF 2020
Parcel ID:
02-2N-11-0087-1200-0160
Name in which Assessed
JOSE BELTRAN BERMUDEZ CAMPOS
Description of Property:
LOT 16, BLOCK 120, COMPASS LAKE HILLS, UNIT FIVE, ACCORDING TO THE MAP OR PLAT THEREOF, RECORDED IN PLAT BOOK A-4, PAGE 130 THROUGH 140, INCLUSIVE, PUBLIC RECORDS OF JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7241
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
2410 OF 2021
NOTICE IS HEREBY GIVEN THAT: SAMMIE D. SIMMONS or DONNA G SIMMONS the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
2410 OF 2021
Parcel ID:
06-2N-11-0000-0050-0230
Name in which Assessed
MORRIS K FORD III
MARGARET F BARNWELL
DEBORAH F WILLIAMS
Description of Property:
A LOT OR PARCEL OF LAND IN JACKSON COUNTY, FLORIDA AND BEING MORE PARTICULARLY DESCRIBED AS FOLLOWS: BEGINNING AT THE NORTHEAST CORNER OF THE NORTHWEST QUARTER OF THE SOUTHEAST QUARTER OF SECTION 6, T2N, R11W, AND THENCE SOUTH 88 DEGREES-18 MINUTES -58 SECONDS WEST ALONG THE NORTH LINE OF SAID FORTY, 948.81 FEET TO THE EASTERLY SIDE OF AN UNPAVED COUNTY ROAD; THENCE SOUTH 17 DEGREES -36 MINUTES 30 SECONDS WEST ALONG THE EASTERLY SIDE OF SAID ROAD, 695.8 FEET TO THE SOUTH LINE OF THE NORTH HALF OF SAID FORTY; THENCE NORTH 87 DEGREES -52 MINUTES -47 SECONDS EAST ALONG THE SOUTH LINE OF SAID TWENTY, 1180 FEET TO THE EAST LINE OF SAID FORTY; THENCE NORTH 1 DEGREES -55 MINUTES -45 SECONDS WEST ALONG THE EAST LINE OF SAID FORTY, 648.27 FEET TO THE POINT OF BEGINNING. SAID PARCEL BEING IN THE NORTHWEST QUARTER OF THE SOUTHEAST QUARTER OF SECTION 6, T2N, R11W AND CONTAINING 15.948 ACRES, MORE OR LESS.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7244
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
2294 OF 2020
NOTICE IS HEREBY GIVEN THAT: CLAUDIUS KESSLER the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
2294 OF 2020
Parcel ID:
02-2N-11-0087-1270-0370
Name in which Assessed
D W MATTHEWS
OPAL D MATTHEWS
Description of Property:
LOT 37, BLOCK 127, COMPASS LAKE HILLS, UNIT FIVE, ACCORDING TO THE MAP OR PLAT THEREOF, RECORDED IN PLAT BOOK A-4, PAGE 130 THROUGH 140, INCLUSIVE, PUBLIC RECORDS OF JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7242
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
2307 OF 2020
NOTICE IS HEREBY GIVEN THAT: CLAUDIUS KESSLER the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
2307 OF 2020
Parcel ID:
02-2N-11-0087-1300-0230
Name in which Assessed
LINDA S BARNES
C LELAND BARNES
Description of Property:
LOT 23, BLOCK 130, COMPASS LAKE HILLS, UNIT FIVE, ACCORDING TO THE MAP OR PLAT THEREOF, RECORDED IN PLAT BOOK A-4, PAGE 130 THROUGH 140, INCLUSIVE, PUBLIC RECORDS OF JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7243
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
2413 OF 2020
NOTICE IS HEREBY GIVEN THAT: CLAUDIUS KESSLER the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
2413 OF 2020
Parcel ID:
02-2N-11-0087-1490-0050
Name in which Assessed
JANE ANN HUTER
Description of Property:
LOT 5, BLOCK 149, COMPASS LAKE HILLS, UNIT FIVE, ACCORDING TO THE MAP OR PLAT THEREOF, RECORDED IN PLAT BOOK A-4, PAGE 130 THROUGH 140, INCLUSIVE, PUBLIC RECORDS OF JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7245
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
2419 OF 2020
NOTICE IS HEREBY GIVEN THAT: CLAUDIUS KESSLER the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
2419 OF 2020
Parcel ID:
02-2N-11-0087-1500-0200
Name in which Assessed
KATY BLAIR
ROBBIE BLAIR
Description of Property:
LOT 20, BLOCK 150, COMPASS LAKE HILLS, UNIT FIVE, ACCORDING TO THE MAP OR PLAT THEREOF, RECORDED IN PLAT BOOK A-4, PAGE 130 THROUGH 140, INCLUSIVE, PUBLIC RECORDS OF JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7246
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
2435 OF 2020
NOTICE IS HEREBY GIVEN THAT: CLAUDIUS KESSLER the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
2435 OF 2020
Parcel ID:
02-2N-11-0087-1520-0550
Name in which Assessed
JOSEPH PASERCHIA
Description of Property:
LOT 55, BLOCK 152, COMPASS LAKE HILLS, UNIT FIVE, ACCORDING TO THE MAP OR PLAT THEREOF, RECORDED IN PLAT BOOK A-4, PAGE 130 THROUGH 140, INCLUSIVE, PUBLIC RECORDS OF JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7247
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
448 OF 2021
NOTICE IS HEREBY GIVEN THAT: SAMMIE D. SIMMONS or DONNA G. SIMMONS the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
448 OF 2021
Parcel ID:
07-2N-09-0000-0070-0050
Name in which Assessed
EVELYN BOGGS FREE
Description of Property:
COMMENCE AT SOUTHWEST CORNER OF SOUTHWEST QUARTER OF SECTION 7, TOWNSHIP 2 NORTH, RANGE 9 WEST AND RUN NORTH 880 FEET FOR THE POINT OF BEGINNING; THENCE RUN NORTH 220 FEET; THENCE RUN EAST 2640 FEET TO THE EAST SIDE OF SOUTHWEST QUARTER OF SECTION 7, TOWNSHIP 2 NORTH, RANGE 9 WEST; THENCE RUN SOUTH 220 FEET; THENCE RUN WEST 2640 FEET TO THE POINT OF BEGINNING. CONTAINING 13.33 ACRES MORE OR LESS.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7248
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
1123 OF 2019
NOTICE IS HEREBY GIVEN THAT: BUFFALO BILL, LLC the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
1123 OF 2019
Parcel ID:
04-4N-10-0343-0000-0115
Name in which Assessed
DAFFIN MERCANTILE CO INC
Description of Property:
COMMENCE AT THE NORTHWEST CORNER OF SECTION 4, TOWNSHIP 4 NORTH, RANGE 10 WEST, JACKSON COUNTY, FLORIDA, AS PER DEPARTMENT OF TRANSPORTATION RIGHT OF WAY PLANS, THENCE SOUTH 03 DEGREES 12 MINUTES 17 SECONDS EAST 646.0 FEET TO THE CENTER LINE OF SURVEY OF STATE ROAD 10, THENCE SOUTH 67 DEGREES 52 MINUTES 47 SECONDS EAST 242.62 FEET, THENCE SOUTH 79 DEGREES 35 MINUTES 47 SECONDS EAST 768.11 FEET, THENCE SOUTH 58 DEGREES 34 MINUTES 47 SECONDS EAST 2044.81 FEET, THENCE SOUTH 33 DEGREES 04 MINUTES 47 SECONDS EAST 783.12 FEET, THENCE SOUTH 71 DEGREES 55 MINUTES 35 SECONDS EAST 1444.64 FEET TO DEPARTMENT OF TRANSPORTATION STATION NO. 23 + 98.90, THENCE SOUTH 16 DEGREES 23 MINUTES 25 SECONDS EAST 26.69 FEET TO THE NORTHEAST CORNER OF LOT #11 OF THE PITTMAN ADDITION TO MARIANNA, FLORIDA, THENCE SOUTH 16 DEGREES 04 MINUTES 51 SECONDS WEST 250.0 FEET TO A CONCRETE MARKER AND CALL THIS THE POINT OF BEGINNING, THENCE NORTH 72 DEGREES 13 MINUTES 35 SECONDS WEST 97.17 FEET TO AN IRON PIPE, THENCE SOUTH 19 DEGREES 52 MINUTES 17 SECONDS WEST 209.02 FEET TO A CONCRETE MARKER, THENCE SOUTH 19 DEGREES 44 MINUTES 47 SECONDS WEST 80.0 FEET TO IRON PIPE., THENCE SOUTH S9 DEGREES 25 MINUTES, 30 SECONDS EAST 118.9 FEET THENCE NORTH 16 DEGREES 04 MINUTES 51 SECONDS EAST 313.06 FEET TO THE POINT OF BEGINNING.
THIS TRACT IS LOCATED WITHIN THE CITY LIMITS OF MARIANNA, FLORIDA, AND WITHIN THE SOUTHEAST QUARTER OF SECTION 4, TOWNSHIP 4 NORTH, RANGE 10 WEST, JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7249
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
1584 OF 2017
NOTICE IS HEREBY GIVEN THAT: MICHAEL J GRAZIOSO the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
1584 OF 2017
Parcel ID:
02-2N-11-0083-10AB-0050
Name in which Assessed
RONALD ROBENOLT
Description of Property:
LOT 5, BLOCK AB, CORRECTED PLAT OF COMPASS LAKE HILLS UNIT TWO, ACCORDING TO THE PLAT THEREOF, AS RECORDED IN PLAT BOOK A-4, PAGES 111A THROUGH 115A, INCLUSIVE, OF THE PUBLIC RECORDS OF JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7250
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
2258 OF 2018
NOTICE IS HEREBY GIVEN THAT: AVK REAL ESTATE, LLC the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
2258 OF 2018
Parcel ID:
02-2N-11-0087-1750-0110
Name in which Assessed
ALAN W PURVIS
SARAH B PURVIS
Description of Property:
LOT 11, BLOCK 175, COMPASS LAKE HILLS UNIT FIVE, ACCORDING TO THE PLAT THEREOF, AS RECORDED IN PLAT BOOK A-4 AT PAGES 130 THROUGH 140, INCLUSIVE, OF THE PUBLIC RECORDS OF JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7251
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
2581 OF 2021
NOTICE IS HEREBY GIVEN THAT: SAMMIE D SIMMONS or DONNA G SIMMONS the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
2581 OF 2021
Parcel ID:
28-5N-11-0000-0020-0000
Name in which Assessed
BESSIE DAVIS ESTATE
MARY RUSS
LLOYD WHITE JR ESTATE
HUBIE WHITE ESTATE
PLUET WHITE ESTATE
OCEE WHITE DIXON ESTATE
MENEFEE WHITE ESTATE
VERNON DAVIS JR
DANA SHINE
TENA WORRELL
BETTY JONES
GLADYS DANIELS
JELMER ZIMMERMAN
JAVIER ZIMMERMAN
Description of Property:
NORTHWEST QUARTER OF NORTHEAST QUARTER OF SECTION 28, TOWNSHIP 5 NORTH, RANGE 11 WEST, JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7253
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
NOTICE OF APPLICATION FOR TAX DEED
CERTIFICATE NO.
2452 OF 2021
NOTICE IS HEREBY GIVEN THAT: MICHAEL J JOHNSON, RESULTS DRIVEN, LLC the holder of the following certificate has filed said certificate for a tax deed to be issued thereon. The certificate number, description of property and the name in which it was assessed are as follows:
Certificate No.
2452 OF 2021
Parcel ID:
14-3N-11-0000-0110-0010
Name in which Assessed
PAMELA S MEDLOCK BOUTWELL ESTATE
Description of Property:
THE SOUTH HALF OF THE EAST HALF OF THE NORTH HALF OF THE SOUTHEAST QUARTER OF THE SOUTHWEST QUARTER, IN SECTION 14, TOWNSHIP 3 NORTH, RANGE 11 WEST, JACKSON COUNTY, FLORIDA.
All of said property being in the County of Jackson, State of Florida.
Unless such certificate shall be redeemed according to law, the property described in such certificate will be sold to the highest bidder at https://jackson.realtaxdeed.com, on the Fourth Tuesday, 05/28/2024 at 11:00 A.M. Central Time or any subsequently scheduled sale date.
Dated this 11th day of April, 2024.
CLAYTON O. ROOKS, III
CLERK OF CIRCUIT & COUNTY COURTS JACKSON, FLORIDA
By: Krystal Graham
Deputy Clerk
L7252
Dates of Publication: 04/18/2024, 04/25/2024, 05/02/2024, 05/09/2024
